Commissioning preparation of a system or systems to allow hydrocarbons or other process fluids to be safely introduced into the system or systems for processing. In this phase testing will focus on systems, including utilities.
Construction Period The term “Construction Period” shall mean the period from the date of this Lease to the date that Landlord completes construction of the Landlord’s Work (including any “Additional Base Building Items”, as defined in Section 3(f) of the Tenant Work Letter), and Common Areas, regardless of the occurrence of any Tenant Delay and without regard to the effect of any provision of this Lease pursuant to which the Premises are deemed to be Ready for Occupancy in advance of its actual occurrence. Notwithstanding any provision of this Lease to the contrary (including Exhibit B), during the Construction Period only, the following provisions shall be applicable:
Construction Phase During Construction, DESIGN/BUILDER shall provide Engineering and Design Professional Services as necessary to complete the Project.
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Production Work Except as agreed to in writing by the Parties pursuant to the "Production Work" section of the Standard Online Commerce Terms & Conditions attached hereto as Exhibit F, MP will be responsible for all production work associated with the Affiliated MP Site, including all related costs and expenses.
Construction Budget Administrative Agent shall have received each of the Construction Budget in form and substance reasonably satisfactory to Administrative Agent (in consultation with the Independent Engineer).
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Annual Operating Budget As soon as available but, in any event, within sixty (60) days prior to (i) the Cooperation Period Commencement Date in respect of the initial Plant to be completed and, thereafter, (ii) the commencement of each Fiscal Year, an annual operating budget (the "Annual Budget") (including budgeted statements of income and sources and uses of cash and balance sheets) prepared by the Borrower and accompanied by a statement of the chief financial officer of the Borrower to the effect that, the best of his or her knowledge, the budget is a reasonable estimate for the period covered thereby. The first Annual Budget shall cover the period from the Cooperation Period Commencement Date through the end of the Fiscal Year in which the Cooperation Period Commencement Date occurs, and, if such period consists of less than six (6) months, for the immediately succeeding Fiscal Year. Each Annual Budget shall contain complete, fair and accurate estimates (by principal components) of Sales Proceeds, Operating and Maintenance Costs and Debt Service for each Month covered by such Annual Budget based on the Borrower's best projections at such time. Unless otherwise consented to by Eximbank, the Annual Budget from year to year shall be based on the same format as the Base Case Forecast, including any amounts allocated for contingencies, and be maintained on the same basis and provide sufficient detail to permit a meaningful comparison. For each Annual Budget that is expected to cover any period occurring after the Disbursement Date, Eximbank (in consultation with the Independent Engineer) shall review such Annual Budget, and Eximbank's response shall not be unreasonably delayed. If Eximbank does not approve an Annual Budget, Eximbank shall notify the Borrower of the items which are disapproved and the reason for such disapproval. Until such Annual Budget is so approved, the Annual Budget most recently in effect shall continue to apply, except that any items of the then proposed Annual Budget that have been approved shall also be given effect. From time to time, but not more frequently than once per Quarter, the Borrower may propose amendments to an Annual Budget, and Eximbank (in consultation with the Independent Engineer) may reject such proposal within thirty (30) Business Days from the date the Borrower submits such proposal if in Eximbank's reasonable judgment such amendment is not reasonably necessary or advisable for operation of the Project and, if no such rejection is made, such amendments shall become effective. Not later than three (3) Business Days after the effective date of each Annual budget and of any amendment thereto, the Borrower shall provide a copy of the same to the Collateral Trustee.
