Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Cloud Computing State Risk and Authorization Management Program In accordance with Senate Bill 475, Acts 2021, 87th Leg., R.S., pursuant to Texas Government Code, Section 2054.0593, Contractor acknowledges and agrees that, if providing cloud computing services for System Agency, Contractor must comply with the requirements of the state risk and authorization management program and that System Agency may not enter or renew a contract with Contractor to purchase cloud computing services for the agency that are subject to the state risk and authorization management program unless Contractor demonstrates compliance with program requirements. If providing cloud computing services for System Agency that are subject to the state risk and authorization management program, Contractor certifies it will maintain program compliance and certification throughout the term of the Contract.
Conditions Precedent to the Obligation of the Company to Sell the Shares The obligation hereunder of the Company to issue and sell the Shares is subject to the satisfaction or waiver, at or before the Closing, of each of the conditions set forth below. These conditions are for the Company’s sole benefit and may be waived by the Company at any time in its sole discretion.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Trustee to Retain Possession of Certain Insurance Policies and Documents The Trustee (or the Custodian, as directed by the Trustee), shall retain possession and custody of the originals (to the extent available) of any Primary Mortgage Insurance Policies, or certificate of insurance if applicable, and any certificates of renewal as to the foregoing as may be issued from time to time as contemplated by this Agreement. Until all amounts distributable in respect of the Certificates have been distributed in full and the Master Servicer otherwise has fulfilled its obligations under this Agreement, the Trustee (or its Custodian, if any, as directed by the Trustee) shall also retain possession and custody of each Mortgage File in accordance with and subject to the terms and conditions of this Agreement. The Master Servicer shall promptly deliver or cause to be delivered to the Trustee (or the Custodian, as directed by the Trustee), upon the execution or receipt thereof the originals of any Primary Mortgage Insurance Policies, any certificates of renewal, and such other documents or instruments that constitute portions of the Mortgage File that come into the possession of the Master Servicer from time to time.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Term of Agreement; Resignation and Removal of the Administrator (a) This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate. (b) Subject to Section 8(e), the Administrator may resign its duties hereunder by providing the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice. (c) Subject to Section 8(e), the Issuing Entity may remove the Administrator without cause by providing the Administrator, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice. (d) Subject to Section 8(e), at the sole option of the Issuing Entity, the Administrator may be removed immediately upon written notice of termination from the Issuing Entity to the Administrator, the Trustee, the Indenture Trustee and the Servicer if any of the following events shall occur: (i) the Administrator shall default in the performance of any of its duties under this Agreement and, after notice of such default, shall not cure such default within ten days (or, if such default cannot be cured in such time, shall not give within ten days such assurance of cure as shall be reasonably satisfactory to the Issuing Entity); (ii) a court having jurisdiction in the premises shall enter a decree or order for relief, and such decree or order shall not have been vacated within 60 days, in respect of the Administrator in any involuntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect or appoint a receiver, liquidator, assignee, custodian, trustee, sequestrator or similar official for the Administrator or any substantial part of its property or order the winding-up or liquidation of its affairs; or (iii) the Administrator shall commence a voluntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect, shall consent to the entry of an order for relief in an involuntary case under any such law, or shall consent to the appointment of a receiver, liquidator, assignee, trustee, custodian, sequestrator or similar official for the Administrator or any substantial part of its property, shall consent to the taking of possession by any such official of any substantial part of its property, shall make any general assignment for the benefit of creditors or shall fail generally to pay its debts as they become due. The Administrator agrees that if any of the events specified in clauses (ii) or (iii) of this subsection shall occur, it shall give written notice thereof to the Issuing Entity, the Servicer, the Trustee and the Indenture Trustee within seven days after the happening of such event. (e) Upon the Administrator’s receipt of notice of termination, pursuant to Sections 8(c) or (d), or the Administrator’s resignation in accordance with this Agreement, the predecessor Administrator shall continue to perform its functions as Administrator under this Agreement, in the case of termination, only until the date specified in such termination notice or, if no such date is specified in a notice of termination, until receipt of such notice and, in the case of resignation, until the later of: (x) the date 45 days from the delivery to the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer of written notice of such resignation (or written confirmation of such notice) in accordance with this Agreement and (y) the date upon which the predecessor Administrator shall become unable to act as Administrator, as specified in the notice of resignation and accompanying Opinion of Counsel. In the event of the Administrator’s termination hereunder, the Issuing Entity shall appoint a successor Administrator acceptable to the Indenture Trustee, and the successor Administrator shall accept its appointment by a written assumption in form acceptable to the Indenture Trustee. In the event that a successor Administrator has not been appointed at the time when the predecessor Administrator has ceased to act as Administrator in accordance with this Section, and if the predecessor Administrator is currently serving as the Servicer under the Transaction Documents, the Indenture Trustee without further action shall automatically be appointed the successor Administrator and the Indenture Trustee shall be entitled to the compensation specified in Section 3. Notwithstanding the above, the Indenture Trustee shall, if it shall be unable so to act, appoint or petition a court of competent jurisdiction to appoint any established institution having a net worth of not less than $50,000,000 and whose regular business shall include the performance of functions similar to those of the Administrator, as the successor to the Administrator under this Agreement. (f) Upon appointment, the successor Administrator (including the Indenture Trustee acting as successor Administrator) shall be the successor in all respects to the predecessor Administrator and shall be subject to all the responsibilities, duties and liabilities arising thereafter relating thereto placed on the predecessor Administrator and shall be entitled to the compensation specified in Section 3 and all the rights granted to the predecessor Administrator by the terms and provisions of this Agreement. (g) Except when and if the Indenture Trustee is appointed successor Administrator, the Administrator may not resign unless it is prohibited from serving as such by law as evidenced by an Opinion of Counsel to such effect delivered to the Indenture Trustee. No resignation or removal of the Administrator pursuant to this Section shall be effective until: (i) a successor Administrator shall have been appointed by the Issuing Entity and (ii) such successor Administrator shall have agreed in writing to be bound by the terms of this Agreement in the same manner as the Administrator is bound hereunder. (h) The appointment of any successor Administrator shall be effective only after satisfaction of the Rating Agency Condition with respect to the proposed appointment.
CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Required Confidentiality Claim Form This is a requirement of the TIPS Contract and is non-negotiable. TIPS provides the required TIPS Confidentiality Claim Form in the "Attachments" section of this solicitation. Vendor must execute this form by either signing and waiving any confidentiality claim, or designating portions of Vendor's proposal confidential. If Vendor considers any portion of Vendor's proposal to be confidential and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s) and orders, Vendor must have identified the claimed confidential materials through proper execution of the Confidentiality Claim Form. If TIPS receives a public information act or similar request, any responsive documentation not deemed confidential by you in this manner will be automatically released. For Vendor documents deemed confidential by you in this manner, TIPS will follow procedures of controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law, including Attorney General determination and opinion. Notwithstanding any other Vendor designation of Vendor's proposal as confidential or proprietary, Vendor’s submission of this proposal constitutes Vendor’s agreement that proper execution of the required TIPS Confidentiality Claim Form is the only way to assert any portion of Vendor's proposal as confidential.
