Minor Damage In the event of loss or damage to the Property or any portion thereof which is not "major" (as hereinafter defined), this Agreement shall remain in full force and effect provided Seller performs any necessary repairs or, at Seller's option, assigns to Purchaser all of Seller's right, title and interest to any claims and proceeds Seller may have with respect to any casualty insurance policies or condemnation awards relating to the premises in question. In the event that Seller elects to perform repairs upon the Property, Seller shall use reasonable efforts to complete such repairs promptly and the date of Closing shall be extended a reasonable time in order to allow for the completion of such repairs. If Seller elects to assign a casualty claim to Purchaser, the Purchase Price shall be reduced by an amount equal to the deductible amount under Seller's insurance policy. Upon Closing, full risk of loss with respect to the Property shall pass to Purchaser.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Major Damage In the event of Major Damage to a Property prior to the Closing Date, then the applicable Seller shall have no obligation to repair such Major Damage and shall notify Purchaser in writing of such damage or destruction (the “Damage Notice”). Within ten (10) days after Purchaser’s receipt of the Damage Notice, Purchaser may elect at its option to give a Termination Notice for the damaged Property to Seller’s Representative. If Purchaser does not elect to terminate this Agreement with respect to the damaged Property, this transaction shall be closed in accordance with the terms of this Agreement either, at the election of the applicable Seller, (a) for the full Purchase Price for the damaged Property notwithstanding any such damage or destruction, and Purchaser shall, at Closing, execute and deliver an assignment and assumption (in a form reasonably required by the applicable Seller) of such Seller’ rights and obligations with respect to the insurance claim and related to such casualty, and thereafter Purchaser shall receive all remaining insurance proceeds pertaining to such claim (plus a credit against the applicable Purchase Price at Closing in the amount of any deductible payable by the applicable Seller in connection therewith and not spent by such Seller for demolition, site cleaning, restoration or other repairs); or (b) Purchaser shall receive a credit against the Base Purchase Price for the damaged Property for the full replacement costs of repair to the subject Property, plus, to the extent covered by such Seller’s insurance policy, any costs required pursuant to local code or zoning requirements, as determined by an independent third party reasonably acceptable to such Seller and Purchaser. In the event a Seller elects to assign such Seller's rights and obligations with respect to the insurance claim and related casualty to Purchaser as provided above, and if an AIMCO employee is the adjuster for the claim related thereto, Sellers covenant and agree that the adjuster shall act in accordance with standard insurance industry protocols in processing such claim (including, without limitation, the time taken to process such claim).
Sprinkler System If there now is or shall be installed in the Building a "sprinkler system", and such system or any of its appliances shall be damaged or injured or not in proper working order by reason of any act or omission of Tenant, Tenant's agents, servants, employees, licensees or visitors, Tenant shall forthwith restore the same to good working condition at its own expense; and if the New York Board of Fire Underwriters or the New York Fire Insurance Rating Organization or any bureau, department or official of the state or city government, shall require or recommend that any changes, modifications, alterations or additional sprinkler heads or other equipment be made or supplied by reason of Tenant's business, or the location of the partitions, trade fixtures, or other contents of the Premises, Tenant shall, at Tenant's expense, promptly make and supply such changes, modifications, alterations, additional sprinkler heads or other equipment.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Landlord's Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.
Emergency Generator Tenant shall have the right to tie into and use the emergency generator to be installed by Landlord as part of the Base Building Work for use by tenants of the Unit (the “Unit Generator”). Tenant shall be responsible, at its sole cost and expense, for installing, maintaining, repairing and replacing its connection between the Premises and the Unit Generator, and all associated cabling. Tenant shall be permitted to use up to an average of three (3) xxxxx per square foot of usable area in the Premises from the Unit Generator, and at no time shall Tenant exceed that use limitation with respect to the Unit Generator. Except to the extent that Tenant ties into the Unit Generator as part of the Initial Tenant Work in accordance with the provisions of the Work Letter, installation of such tie-in and any related cabling, conduit and appurtenances will be governed by the applicable provisions of this Lease relating to Tenant Work. Tenant will submit to Landlord at least thirty (30) days prior to the proposed installation date Tenant’s proposed plans and specifications relating to the tie-in to the Unit Generator and all associated lines. Tenant may not commence any work to tie into the Unit Generator until it has received Landlord’s prior written approval (not to be unreasonably withheld, delayed or conditioned) of such plans and specifications. Tenant, at its sole cost and expense, shall comply with all applicable Legal Requirements and Title Matters and Landlord’s reasonable directives relating to the installation, operation, maintenance and repair of such tie-in, including (i) obtaining and maintaining (or causing to be obtained and maintained) and complying with the provisions of all applicable permits relating to the tie into and use of the Unit Generator. Tenant may not use the Unit Generator for any purpose other than solely in connection with Tenant’s occupancy of the Premises for the Permitted Use and in accordance with any applicable permit(s) pertaining to the Unit Generator. Except for permitted subtenants and assignees. Tenant may not use the Unit Generator to serve other occupant(s) of the Development.
Tenant's Responsibility Landlord shall not be liable to Tenant or to any other person for (i) damage to property or injury or death to persons due to the condition of the Leased Premises, the Building or the common areas, or (ii) the occurrence of any accident in or about the Leased Premises or the common areas, or (iii) any act or neglect of Tenant or any other tenant or occupant of the Building or of any other person, unless such damage, injury or death is directly and solely the result of Landlord's negligence; and Tenant hereby releases Landlord from any and all liability for the same. Tenant shall be liable for, and shall indemnify and defend Landlord from, any and all liability for (i) any act or neglect of Tenant and any person coming on the Leased Premises or common areas by the license of Tenant, express or implied, (ii) any damage to the Leased Premises, and (iii) any loss of or damage or injury to any person (including death resulting therefrom) or property occurring in, on or about the Leased Premises, regardless of cause, except for any loss or damage covered by Landlord's all risk coverage insurance as provided in Section 8.02 and except for that caused solely and directly by Landlord's negligence. This provision shall survive the expiration or earlier termination of this Lease.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Remedial Actions Relating to Hazardous Materials Activities Borrower shall, in compliance with all applicable Environmental Laws, promptly undertake, and shall cause each of its Subsidiaries promptly to undertake, any and all investigations, studies, sampling, testing, abatement, cleanup, removal, remediation or other response actions necessary to remove, remediate, clean up or xxxxx any Hazardous Materials Activity on, under or about any Facility that is in violation of any Environmental Laws or that presents a material risk of giving rise to an Environmental Claim. If Borrower or any of its Subsidiaries undertakes any such action with respect to any Hazardous Materials, Borrower or such Subsidiary shall conduct and complete such action in compliance with all applicable Environmental Laws and in accordance with the policies, orders and directives of all federal, state and local Government Authorities except when, and only to the extent that, Borrower’s or such Subsidiary’s liability with respect to such Hazardous Materials Activity is being diligently contested in good faith and by appropriate proceedings by Borrower or such Subsidiary.
