Indemnity of Project Manager Sample Clauses

Indemnity of Project Manager. Owner shall, and Owner does hereby agree to, indemnify Project Manager against, and hold, save and defend Project Manager harmless from, any and all claims, demands, actions, causes of action, suits, liabilities, damages, losses, costs and expenses of any kind or nature whatsoever (including, without limitation, reasonable attorneys’ fees and court costs incurred in enforcing this indemnity and otherwise) which Project Manager may suffer or incur, or which may be asserted against Project Manager, whether meritorious or not, and which arise in connection with the Project or the performance by Project Manager of any of its duties and obligations under this Agreement, which indemnity shall continue notwithstanding the expiration or earlier termination of this Agreement with respect to any occurrence preceding such expiration or termination, provided, however, that in no event shall the indemnity provided under this Section 12.3 extend to a claim, demand, action, cause of action, suit, liability, damage, loss, cost or expense (i) if and to the extent the same is within the scope of the indemnity of Owner by Project Manager pursuant to Section 12.4 of this Agreement, or (ii) if and to the extent the same is caused by any default, negligent act or willful misconduct of Project Manager or its agents or employees, or by any failure to comply with the standard of care set forth in Section 12.1 of this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Indemnity of Project Manager

  • RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.

  • Indemnification by Subcontractors To the fullest extent permitted by law, an Interconnection Party that uses a subcontractor to carry out any of the Interconnection Party’s obligations under this Appendix 2 shall require each of its subcontractors to indemnify, hold harmless and defend each other Interconnection Party, its representatives and assigns from and against any and all claims and/or liability for damage to property, injury to or death of any person, including the employees of any Interconnection Party or of any Affiliate of any Interconnection Party, or any other liability incurred by the other Interconnection Party or any of its Affiliates, including all expenses, legal or otherwise, to the extent caused by any act or omission, negligent or otherwise, by such subcontractor and/or its officers, directors, employees, agents and assigns, that arises out of or is connected with the operation of the facilities of either Interconnected Entity described in this Appendix 2; provided, however, that no Interconnection Party or Affiliate thereof shall be entitled to indemnity under this Section 18.3 in respect of any injury, loss, or damage to the extent that such loss, injury, or damage results from the negligence or willful misconduct of the Interconnection Party or Affiliate seeking indemnity.

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:

  • Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.

  • COMPENSATION FOR CONSTRUCTION PHASE SERVICES 5.1 For the Construction Manager’s performance of the Work as described in Section 2.3, the Owner shall pay the Construction Manager the Contract Sum in current funds. The Contract Sum is the Cost of the Work as defined in Section 6.1.1 plus the Construction Manager’s Fee.

  • Environmental constraints and management Describe or cross refer to environmental constraints applicable to the Contractor’s plan and his activities on the Affected Property and how they should be managed. Include here or cross refer to an Annexure to the Service Information. The Contractor shall comply with the environmental criteria and constraints stated in Annexure

  • Contractors Submission Respecting the Agreement The Contractor shall, as part of the Contractor's submission respecting this Contract, complete the attached Schedule B, Identification of Principles; Schedule C, Schedule of Tendered Unit Prices; Schedule D, Schedule of Equipment to be used on the work; and Schedule E, Schedule of Sub-Contractors. The Contract including all appended schedules shall be completed in complete conformity with the instructions to bidders contained in the document entitled "General Provisions and Contract Specification for Highway Construction". In presenting the Contractor’s submission for consideration by the Minister, the Contractor understands that until, and unless, the Contract is endorsed by the Minister, no Contract between the parties shall exist and the Minister shall not be bound to endorse any Contract.

  • Environmental Indemnification Borrower shall, at its sole cost and expense, protect, defend, indemnify, release and hold harmless the Indemnified Parties from and against any and all Losses and costs of Remediation (whether or not performed voluntarily), engineers' fees, environmental consultants' fees, and costs of investigation (including but not limited to sampling, testing, and analysis of soil, water, air, building materials and other materials and substances whether solid, liquid or gas) imposed upon or incurred by or asserted against any Indemnified Parties, and directly or indirectly arising out of or in any way relating to any one or more of the following: (a) any presence of any Hazardous Substances in, on, above, or under the Property; (b) any past, present or threatened Release of Hazardous Substances in, on, above, under or from the Property; (c) any activity by Borrower, any Person affiliated with Borrower or any tenant or other user of the Property in connection with any actual, proposed or threatened use, treatment, storage, holding, existence, disposition or other Release, generation, production, manufacturing, processing, refining, control, management, abatement, removal, handling, transfer or transportation to or from the Property of any Hazardous Substances at any tine located in, under, on or above the Property; (d) any activity by Borrower, any Person affiliated with Borrower or any tenant or other user of the Property in connection with any actual or proposed Remediation of any Hazardous Substances at any time located in, under, on or above the Property, whether or not such Remediation is voluntary or pursuant to court or administrative order, including but not limited to any removal, remedial or corrective action; (e) any past or present non-compliance or violations of any Environmental Laws (or permits issued pursuant to any Environmental Law) in connection with the Property or operations thereon, including but not limited to any failure by Borrower, any Affiliate of Borrower or any tenant or other user of the Property to comply with any order of any Governmental Authority in connection with any Environmental Laws; (f) the imposition, recording or filing of any Environmental Lien encumbering the Property; (g) any administrative processes or proceedings or judicial proceedings in any way connected with any matter addressed in Article 8 and this SECTION 9.4; (h) any past, present or threatened injury to, destruction of or loss of natural resources in any way connected with the Property, including but not limited to costs to investigate and assess such injury, destruction or loss; (i) any acts of Borrower or other users of the Property in arranging for disposal or treatment, or arranging with a transporter for transport for disposal or treatment, of Hazardous Substances owned or possessed by such Borrower or other users, at any facility or incineration vessel owned or operated by another Person and containing such or any similar Hazardous Substance; (j) any acts of Borrower or other users of the Property, in accepting any Hazardous Substances for transport to disposal or treatment facilities, incineration vessels or sites selected by Borrower or such other users, from which there is a Release, or a threatened Release of any Hazardous Substance which causes the incurrence of costs for Remediation; (k) any personal injury, wrongful death, or property damage arising under any statutory or common law or tort law theory, including but not limited to damages assessed for the maintenance of a private or public nuisance or for the conducting of an abnormally dangerous activity on or near the Property; and (1) any misrepresentation or inaccuracy in any representation or warranty or material breach or failure to perform any covenants or other obligations pursuant to Article 8. Notwithstanding the foregoing, Borrower shall not be liable under this SECTION 9.4 for any Losses or costs of Remediation to which the Indemnified Parties may become subject to the extent such Losses or costs of Remediation arise by reason of the gross negligence, illegal acts, fraud of willful misconduct of the Indemnified Parties. This indemnity shall survive any termination, satisfaction or foreclosure of this Security Instrument, subject to the provisions of SECTION 10.5.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Indemnification and Liability A. Neither the Contractor, OSC, nor the State shall be liable for any delay or failure in performance beyond its control resulting from acts of war, hostility or sabotage; act of God; electrical, internet or telecommunications outage that is not caused by the obligated party; or government restrictions, or other force majeure. The parties shall use reasonable efforts to eliminate or minimize the effect of such force majeure events upon performance of their respective duties under this Agreement. If such event continues for more than 90 days, either party may terminate all or any agreed upon portion of the Agreement immediately upon written notice. This section does not excuse either party’s obligation to take reasonable steps to follow its normal disaster recovery procedures, or OSC’s obligation to pay for Services provided by the Contractor which have been approved by OSC.

Time is Money Join Law Insider Premium to draft better contracts faster.