Informal Dispute Resolution (a) Prior to the initiation of formal dispute resolution procedures (i.e., arbitration), the Parties shall first attempt to resolve their dispute at the senior manager level. If that level of dispute resolution is not successful, the Parties shall proceed informally, as follows: (i) Upon the written request of either Party, each Party shall appoint a designated representative who does not otherwise devote substantially full time to performance under this Agreement, whose task it will be to meet for the purpose of endeavoring to resolve such dispute. (ii) The designated representatives shall meet as often as the Parties reasonably deem necessary in order to gather and furnish to the other all information with respect to the matter in issue that the Parties believe to be appropriate and germane in connection with its resolution. The representatives shall discuss the problem and attempt to resolve the dispute without the necessity of any formal proceeding. (iii) During the course of discussion, all reasonable requests made by one Party to another for non-privileged non-confidential information reasonably related to this Agreement shall be honored so that each of the Parties may be fully advised of the other's position. (iv) The specific format for the discussions shall be left to the discretion of the designated representatives. (b) Prior to instituting formal proceedings, the Parties will first have their chief executive officers meet to discuss the dispute. This requirement shall not delay the institution of formal proceedings past any statute of limitations expiration or for more than fifteen (15) days. (c) Subject to Subsection (b), formal proceedings for the resolution of a dispute may not be commenced until the earlier of: (i) The designated representatives concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or (ii) Thirty (30) days after the initial written request to appoint a designated representative pursuant to Subsection (a), above, (this period shall be deemed to run notwithstanding any claim that the process described in this Section 11.2 was not followed or completed). (d) This Section 11.2 shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to avoid the expiration of any applicable limitations period, or to preserve a superior position with respect to other creditors or as provided in Section 11.6(a).
Dispute Resolutions Parties agree to arbitration of dispute in Houston, Texas, USA.
Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager. 2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation. 3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief. 4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Alternate Dispute Resolution In the event of any issue of controversy under this Agreement, the PARTIES may pursue Alternate Dispute Resolution procedures to voluntarily resolve those issues. These procedures may include, but are not limited to, conciliation, facilitation, mediation, and fact finding.
Formal Dispute Resolution 10.6.1 If the Parties are unable to resolve the dispute through the informal procedure described in Section 10.5, then either Party may invoke the formal Dispute Resolution procedures described in this Section 10.6. Unless agreed among all Parties, formal Dispute Resolution procedures, including arbitration or other procedures as appropriate, may be invoked not earlier than sixty (60) calendar days after receipt of the letter initiating Dispute Resolution under Section 10.3.
I2 Dispute Resolution The Parties shall attempt in good faith to negotiate a settlement to any dispute between them arising out of or in connection with the Contract within twenty (20) Working Days of either Party notifying the other of the dispute and such efforts shall involve the escalation of the dispute to the finance director of the Contractor and the commercial director of the Authority.
Initial Dispute Resolution If a dispute arises out of or relates to this Contract or its breach, the parties shall endeavor to settle the dispute first through direct discussions between the parties’ representatives who have the authority to settle the dispute. If the parties’ representatives are not able to promptly settle the dispute, they shall refer the dispute to the senior administrators of the parties who have the authority to settle the dispute, who shall meet within fourteen days thereafter. If the dispute is not settled by the senior administrators, the parties may submit the dispute to mediation in accordance with Paragraph 5.2.3.2.
Governing Law; Dispute Resolution (a) This Limited Guarantee shall be interpreted, construed and governed by and in accordance with the Laws of the State of New York without regard to the conflicts of law principles thereof that would subject such matter to the Laws of another jurisdiction other than the State of New York. (b) Any disputes, actions and proceedings against any party or arising out of or in any way relating to this Limited Guarantee shall be submitted to the Hong Kong International Arbitration Centre (the “HKIAC”) and resolved in accordance with the Arbitration Rules of HKIAC in force at the relevant time (the “Rules”) and as may be amended by this Section 10(b). The place of arbitration shall be Hong Kong. The official language of the arbitration shall be English and the arbitration tribunal shall consist of three arbitrators (each, an “Arbitrator”). The claimant(s), irrespective of number, shall nominate jointly one Arbitrator; the respondent(s), irrespective of number, shall nominate jointly one Arbitrator; and a third Arbitrator will be nominated jointly by the first two Arbitrators and shall serve as chairman of the arbitration tribunal. In the event the claimant(s) or respondent(s) or the first two Arbitrators shall fail to nominate or agree on the joint nomination of an Arbitrator or the third Arbitrator within the time limits specified by the Rules, such Arbitrator shall be appointed promptly by the HKIAC. The arbitration tribunal shall have no authority to award punitive or other punitive-type damages. The award of the arbitration tribunal shall be final and binding upon the disputing parties. Any party to an award may apply to any court of competent jurisdiction for enforcement of such award and, for purposes of the enforcement of such award, the parties irrevocably and unconditionally submit to the jurisdiction of any court of competent jurisdiction and waive any defenses to such enforcement based on lack of personal jurisdiction or inconvenient forum. (c) Notwithstanding the foregoing, the parties hereto consent to and agree that in addition to any recourse to arbitration as set out in Section 10(b), any party may, to the extent permitted under the Laws of the jurisdiction where application is made, seek an interim injunction from a court or other authority with competent jurisdiction and, notwithstanding that this Agreement is governed by the Laws of the State of New York, a court or authority hearing an application for injunctive relief may apply the procedural Law of the jurisdiction where the court or other authority is located in determining whether to grant the interim injunction. For the avoidance of doubt, this Section 10(c) is only applicable to the seeking of interim injunctions and does not restrict the application of Section 10(b) in any way.
Central Dispute Resolution Committee a) There shall be established a Central Dispute Resolution Committee (CDRC), which shall be composed of two (2) representatives from each of the central parties, and two (2) representatives of the Crown. b) The Committee shall meet at the request of one of the central parties. c) The central parties shall each have the following rights: i. To file a dispute as a grievance with the Committee. ii. To engage in settlement discussions, and to mutually settle a grievance with the consent of the Crown. iii. To withdraw a grievance. iv. To mutually agree to refer a grievance to the local grievance procedure. v. To mutually agree to voluntary mediation. vi. To refer a grievance to final and binding arbitration at any time. d) The Crown shall have the following rights: i. To give or withhold approval to any proposed settlement between the central parties. ii. To participate in voluntary mediation. iii. To intervene in any matter referred to arbitration. e) Only a central party may file a grievance and refer it to the Committee for discussion and review. No grievance can be referred to arbitration without three (3) days prior notice to the Committee. f) It shall be the responsibility of each central party to inform their respective local parties of the Committee’s disposition of the dispute at each step in the central dispute resolution process including mediation and arbitration, and to direct them accordingly. g) Each of the central parties and the Crown shall be responsible for their own costs for the central dispute resolution process.
Dispute Resolution All or any disputes arising out or touching upon or in relation to the terms and conditions of this Agreement, including the interpretation and validity of the terms thereof and the respective rights and obligations of the Parties, shall be settled amicably by mutual discussion, failing which the same shall be settled through the adjudicating officer appointed under the Act.
