Interest on Pending Liquidated Damages Sample Clauses

Interest on Pending Liquidated Damages. (1) If it should later be determined in the dispute process that funds collected by the State to pay liquidated damages assessment should be refunded, the State shall pay interest accruing from the date of offset or collection. The interest rate paid shall be the average rate for investment in the Pooled Money Investment Fund (PMIF) in effect for the month in which the assessment was offset or otherwise collected. When a liquidated damages assessment is offset or otherwise collected over a period of two (2) or more months, the interest rate paid by the State shall be the average rate for investment in the PMIF in effect for the first (1st) month in which the assessment was offset or otherwise collected, revised quarterly for the period of time the assessment was retained by the State. (2) The Contractor shall pay interest to the State on all liquidated damages assessments which are not either paid or offset against payment due to the Contractor within thirty (30) calendar days of the date of receipt of the assessment notice. The interest rate paid shall be the average rate for investment in the PMIF in effect for the month of assessment. If the Contractor’s continuing liability for one (1) particular liquidated damages assessment extends over a period of two (2) or more months, the interest rate shall be the average for investment in the PMIF for the first (1st) month in which liquidated damages were assessed, revised quarterly over the period the assessment remained uncollected. (3) Interest accrues during all periods of time in which the liquidated damages assessment is unpaid or otherwise uncollected. For instance, interest accrues during periods in which collection of the assessment has been suspended, pending the outcome of the dispute or appeal. (4) If a reduction in the final amount of liquidated damages is finally determined, the interest shall be prorated unless impractical to do so.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Interest on Pending Liquidated Damages

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.

  • Interest on Payments Any payment by the Receiver pursuant to Section 2.6(d) shall be made together with interest on the amount thereof that accrues with effect from five (5) Business Days after the date on which payment was agreed or determined to be due until such amount is paid. The annual interest rate shall be determined by the Receiver based on the coupon equivalent of the three (3)-month U.S. Treasury Xxxx Rate in effect as of the first Business Day of each Calendar Quarter during which such interest accrues as reported in the Federal Reserve Board Statistical Release for Selected Interest Rates H.15 opposite the caption “Treasury bills (secondary market), 3-Month” or, if not so reported for such day, for the next preceding Business Day for which such rate was so reported.

  • INTEREST ON ARREARS Any interest instalment unpaid on maturity shall yield interest, of right and without formal notice, at the same rate as applicable to the portion of the loan whose interest is unpaid on maturity, such interest being payable to the Lender on request.

  • Interest on Delinquent Payments Without waiving any other right or action available to Authority, in the event of default of Company's payment of Rents or other charges hereunder, and in the event Company is delinquent in paying to Authority any Rents or other charges for a period of five (5) days after the payment is due, Authority reserves the right to charge Company interest thereon from the date the Rents or other charges became due to the date of payment at one and one-half percent (1.5%) per month, to the maximum extent permitted by Applicable Law.

  • Interest on Unpaid Balances Interest on any unpaid amount (including amounts placed in escrow) shall be calculated in accordance with the method specified for interest on refunds in the Commission’s regulations at 18 C.F.R. § 35.19a (a)(2)(iii). Interest on unpaid amounts shall be calculated from the due date of the xxxx to the date of payment. Invoices shall be considered as having been paid on the date of receipt of payment.

  • Interest on late payment Subject to clause 9.7, the Trader or the Distributor (as the case may be) must pay any Tax Invoice issued under this clause 9. If any part of a Tax Invoice that is properly due in accordance with this Agreement is not paid by the due date, Default Interest may be charged on the outstanding amount for the period that the Tax Invoice remains unpaid.

  • Interest on Late Payments a. State Agencies The payment of interest on certain payments due and owed by Agency may be made in accordance with Article 11-A of the State Finance Law (SFL §179-d et. Seq.) and Title 2 of the New York Code of Rules and Regulations, Part 18 (Implementation of Prompt Payment Legislation -2 NYCRR §18.1 et seq.).

  • Interest on Overdue Payments (a) If the User fails to pay an invoice by the Due Date, the User must, if required by the Service Provider, pay the Service Provider interest on any amount outstanding. (b) Interest will be calculated from the Due Date to the actual date of payment (both inclusive) at an annual percentage rate equal to the aggregate of: (i) the corporate overdraft reference rate (monthly charging cycle) applied by the Commonwealth Bank of Australia (Bank) as at the Due Date (or if the Bank ceases to quote such a rate, then the rate which in the opinion of the Bank is equivalent to such rate in respect of similar overdraft accommodation) expressed as a percentage; plus (ii) 2 per cent per annum.

  • Interest on Unpaid Amounts Any amount which has become payable pursuant to the terms of this Agreement or any decision by arbitrators or judgment by a court of law pursuant to this Section 11 but which has not been timely paid shall bear interest at the prime rate in effect at the time such amount first becomes payable, as quoted by the Bank, except as otherwise provided in Sections 5(g), 6(d) and 7(g) of this Agreement (concerning interest payable with respect to certain delayed payments that are subject to Section 409A of the Code).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!