Application of Amounts in Trust Accounts (a) For so long as any Notes are outstanding, on each Payment Date, the Indenture Trustee will distribute to the Certificateholders, on a pro rata basis, based on the Percentage Interests thereof, the amounts distributable thereto pursuant to Section 5.06 of the Sale and Servicing Agreement and Section 3.01 of the Indenture. From and after the date on which the Notes of all Classes have been paid in full, the Paying Agent shall distribute to the Certificateholders (i) amounts released to the Trust pursuant to Sections 4.02 and 8.05(b) of the Indenture and Section 5.01(d) of the Sale and Servicing Agreement and (ii) amounts that are distributable to the Certificateholders in accordance with the instructions of the Servicer pursuant to Section 5.06 of the Sale and Servicing Agreement.
(b) On each Payment Date, the Owner Trustee shall send to the Certificateholders the statement provided to the Owner Trustee by the Servicer pursuant to Section 5.09 of the Sale and Servicing Agreement with respect to such Payment Date.
(c) In the event that any withholding tax is imposed on the Trust’s distributions (or allocations of income) to a Certificateholder, such tax shall reduce the amount otherwise distributable to the Certificateholders in accordance with this Section. The Owner Trustee and Paying Agent (and the Indenture Trustee, to the extent the Indenture Trustee is then making distributions to Certificateholders) are hereby authorized and directed to retain from amounts otherwise distributable to the Certificateholders sufficient funds for the payment of any tax that is legally owed by the Trust (but such authorization shall not prevent the Owner Trustee from contesting any such tax in appropriate proceedings, and withholding payment of such tax, if permitted by law, pending the outcome of such proceedings). The amount of any withholding tax imposed with respect to a Certificateholder shall be treated as cash distributed to such Certificateholder at the time it is withheld by the Trust and remitted to the appropriate taxing authority. If there is a possibility that withholding tax is payable with respect to any distribution (such as any distribution to a Non-U.S. Person), in order to comply with applicable law, the Owner Trustee may, in its sole discretion and without liability, withhold such amounts in accordance with this paragraph (c). In the event that a Certificateholder wishes to apply for a refund of any such withholding tax, the Owner Trustee shall reasonably cooperate with such Certificateholder in making such claim so long as such Certificateholder agrees to reimburse the Owner Trustee for any out-of-pocket expenses incurred in connection therewith.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Application of Funds in the Collection Account The Master Servicer may, from time to time, make, or cause to be made, withdrawals from the Collection Account for the following purposes:
(i) to reimburse itself or any Servicer for Advances made by it or by such Servicer pursuant to Section 5.04 or the applicable Servicing Agreement; provided, however, that the Master Servicer’s right to reimburse itself pursuant to this subclause is limited to amounts received on or in respect of particular Mortgage Loans (including, for this purpose, Liquidation Proceeds and amounts representing Insurance Proceeds with respect to the property subject to the related Mortgage) which represent late recoveries (net of the applicable Servicing Fee and the Master Servicing Fee) of payments of principal or interest respecting which any such Advance was made; provided, further, that following the final liquidation of a Mortgage Loan, the Master Servicer may reimburse itself for previously unreimbursed Advances in excess of Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loans from any funds in the Collection Account, it being understood, in the case of any such reimbursement, that the Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(ii) to reimburse itself or any Servicer for any Servicing Advances made by it or by such Servicer that it or such Servicer determines in good faith will not be recoverable from amounts representing late recoveries of payments of principal or interest respecting the particular Mortgage Loan as to which such Servicing Advance was made or from Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loan, it being understood, in the case of any such reimbursement, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(iii) to reimburse itself or any Servicer from Liquidation Proceeds for Liquidation Expenses and for amounts expended by it pursuant to Sections 9.20 and 9.22(a) or the applicable Servicing Agreement in good faith in connection with the restoration of damaged property and, to the extent that Liquidation Proceeds after such reimbursement exceed the unpaid principal balance of the related Mortgage Loan, together with accrued and unpaid interest thereon at the applicable Mortgage Rate less the applicable Servicing Fee and the Master Servicing Fee for such Mortgage Loan to the Due Date next succeeding the date of its receipt of such Liquidation Proceeds, to pay to itself out of such excess the amount of any unpaid assumption fees, late payment charges or other Mortgagor charges on the related Mortgage Loan and to retain any excess remaining thereafter as additional servicing compensation, it being understood, in the case of any such reimbursement or payment, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders;
(iv) to reimburse itself or any Servicer for expenses incurred by and recoverable by or reimbursable to it or such Servicer pursuant to Section 9.04, 9.05, 9.06, 9.16 or 9.22(a) or pursuant to the applicable Servicing Agreement, and to reimburse itself for any expenses reimbursable to it pursuant to Section 10.01(c);
(v) to pay to the applicable Person, with respect to each Mortgage Loan or REO Property acquired in respect thereof that has been repurchased by such Person pursuant to this Agreement, all amounts received thereon and not distributed on the date on which the related repurchase was effected;
(vi) subject to Section 5.05, to pay to itself income earned on the investment of funds deposited in the Collection Account;
(vii) to make payments to the Trustee for deposit into the Certificate Account in the amounts and in the manner provided for in Section 4.01(c);
(viii) to make distributions of any Retained Interest to the Retained Interest Holder on each Distribution Date (other than any Retained Interest not deposited into the Collection Account in accordance with Section 4.01(d)(iii));
(ix) to make payment to itself, the Trustee and others pursuant to any provision of this Agreement;
(x) to withdraw funds deposited in error in the Collection Account;
(xi) to clear and terminate the Collection Account pursuant to Section 7.02;
(xii) to reimburse a successor Master Servicer (solely in its capacity as successor Master Servicer), for any fee or advance occasioned by a termination of the Master Servicer, and the assumption of such duties by the Trustee or a successor Master Servicer appointed by the Trustee pursuant to Section 6.14, in each case to the extent not reimbursed by the terminated Master Servicer, it being understood, in the case of any such reimbursement or payment, that the right of the Master Servicer or the Trustee thereto shall be prior to the rights of the Certificateholders; and
(xiii) to reimburse any Servicer for such amounts as are due thereto under the applicable Servicing Agreement and have not been retained by or paid to such Servicer to the extent provided in such Servicing Agreement. If provided in the related Servicing Agreement, each Servicer shall be entitled to retain as additional servicing compensation any Prepayment Interest Excess (to the extent not offset by Prepayment Interest Shortfalls). In the event that the Master Servicer fails on any Deposit Date to remit to the Trustee any amounts required to be so remitted to the Trustee pursuant to subclause (vii) by 12 noon (New York time) on such date, the Master Servicer shall pay the Trustee, for the account of the Trustee, interest calculated at the “prime rate” (as published in the “Money Rates” section of The Wall Street Journal) on such amounts not timely remitted for the period from and including that Deposit Date to but not including the related Distribution Date. In connection with withdrawals pursuant to subclauses (i), (iii), (iv) and (vi) above, the Master Servicer’s or Servicer’s entitlement thereto is limited to collections or other recoveries on the related Mortgage Loan, except as provided herein. The Master Servicer shall therefore keep and maintain a separate accounting for each Mortgage Loan it master services for the purpose of justifying any withdrawal from the Collection Account it maintains pursuant to subclauses (i), (iii), (iv) and (vi) above.
Calculation of Amounts; Binding Effect of Interpretations and Actions of Master Servicer The Master Servicer will compute the amount of all distributions to be made on the Certificates and all losses to be allocated to the Certificates. In the event that the Master Servicer concludes that any ambiguity or uncertainty exists in any provisions of this Agreement relating to distributions to be made on the Certificates, the allocation of losses to the Certificates or otherwise, the interpretation of such provisions and any actions taken by the Master Servicer in good faith to implement such interpretation shall be binding upon Certificateholders.
No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Applications of Proceeds The proceeds of any such sale, lease or other disposition of the Collateral hereunder shall be applied first, to the expenses of retaking, holding, storing, processing and preparing for sale, selling, and the like (including, without limitation, any taxes, fees and other costs incurred in connection therewith) of the Collateral, to the reasonable attorneys' fees and expenses incurred by the Secured Party in enforcing its rights hereunder and in connection with collecting, storing and disposing of the Collateral, and then to satisfaction of the Obligations, and to the payment of any other amounts required by applicable law, after which the Secured Party shall pay to the Company any surplus proceeds. If, upon the sale, license or other disposition of the Collateral, the proceeds thereof are insufficient to pay all amounts to which the Secured Party is legally entitled, the Company will be liable for the deficiency, together with interest thereon, at the rate of 15% per annum (the "Default Rate"), and the reasonable fees of any attorneys employed by the Secured Party to collect such deficiency. To the extent permitted by applicable law, the Company waives all claims, damages and demands against the Secured Party arising out of the repossession, removal, retention or sale of the Collateral, unless due to the gross negligence or willful misconduct of the Secured Party.
Allocation of Proceeds If an Event of Default exists, all payments received by the Administrative Agent (or any Lender as a result of its exercise of remedies permitted under Section 3.3) under any of the Loan Documents, in respect of any Guaranteed Obligations shall be applied in the following order and priority:
(a) to payment of that portion of the Guaranteed Obligations constituting fees, indemnities, expenses and other amounts, including attorney fees, payable to the Administrative Agent in its capacity as such, the Issuing Bank in its capacity as such and the Swingline Lender in its capacity as such, ratably among the Administrative Agent, the Issuing Bank and Swingline Lender in proportion to the respective amounts described in this clause (a) payable to them;
(b) to payment of that portion of the Guaranteed Obligations constituting fees, indemnities and other amounts (other than principal and interest) payable to the Lenders under the Loan Documents, including attorney fees, ratably among the Lenders in proportion to the respective amounts described in this clause (b) payable to them;
(c) to the payment of that portion of the Guaranteed Obligations constituting accrued and unpaid interest on the Swingline Loans;
(d) to payment of that portion of the Guaranteed Obligations constituting accrued and unpaid interest on the Loans and Reimbursement Obligations, ratably among the Lenders and the Issuing Bank in proportion to the respective amounts described in this clause (d) payable to them;
(e) to the payment of that portion of the Guaranteed Obligations constituting unpaid principal of the Swingline Loans;
(f) to payment of that portion of the Guaranteed Obligations constituting unpaid principal of the Loans, Reimbursement Obligations, other Letter of Credit Liabilities and payment obligations then owing under Specified Derivatives Contracts, ratably among the Lenders, the Issuing Bank, and the Specified Derivatives Providers and in proportion to the respective amounts described in this clause (f) payable to them; provided, however, to the extent that any amounts available for distribution pursuant to this clause are attributable to the issued but undrawn amount of an outstanding Letter of Credit, such amounts shall be paid to the Administrative Agent for deposit into the Letter of Credit Collateral Account; and
(g) the balance, if any, after all of the Guaranteed Obligations have been paid in full, to the Borrower or as otherwise required by Applicable Law. Notwithstanding the foregoing, Guaranteed Obligations arising under Specified Derivatives Contracts shall be excluded from the application described above if the Administrative Agent has not received written notice thereof, together with such supporting documentation as the Administrative Agent may request, from the applicable Specified Derivatives Provider, as the case may be. Each Specified Derivatives Provider not a party to this Agreement that has given the notice contemplated by the preceding sentence shall, by such notice, be deemed to have acknowledged and accepted the appointment of the Administrative Agent pursuant to the terms of Article XII for itself and its Affiliates as if a “Lender” party hereto.
Trustee Not Responsible for Recitals, Disposition of Securities or Application of Proceeds Thereof The recitals contained herein and in the Securities, except the Trustee’s certificates of authentication, shall be taken as the statements of the Issuer, and the Trustee assumes no responsibility for the correctness of the same. The Trustee makes no representation as to the validity or sufficiency of this Indenture or of the Securities. The Trustee shall not be accountable for the use or application by the Issuer of any of the Securities or of the proceeds thereof.
Application of Proceeds Subject to the terms of the First Lien Intercreditor Agreement and the Second Lien Intercreditor Agreement, in each case, if executed, any amount received by the Administrative Agent or the Collateral Agent from any Credit Party (or from proceeds of any Collateral) following any acceleration of the Obligations under this Agreement or any Event of Default with respect to the Borrower under Section 11.4 shall be applied:
(i) first, to the payment of all reasonable and documented costs and expenses incurred by the Administrative Agent or the Collateral Agent in connection with any collection or sale of the Collateral or otherwise in connection with any Credit Document, including all court costs and the reasonable fees and expenses of its agents and legal counsel, the repayment of all advances made by the Administrative Agent or the Collateral Agent hereunder or under any other Credit Document on behalf of any Credit Party and any other reasonable and documented costs or expenses incurred in connection with the exercise of any right or remedy hereunder or under any other Credit Document to the extent reimbursable hereunder or thereunder;
(ii) second, to the Secured Parties, an amount (x) equal to all Obligations owing to them on the date of any distribution and (y) sufficient to Cash Collateralize all Letters of Credit Outstanding on the date of any distribution, and, if such moneys shall be insufficient to pay such amounts in full and Cash Collateralize all Letters of Credit Outstanding, then ratably (without priority of any one over any other) to such Secured Parties in proportion to the unpaid amounts thereof and to Cash Collateralize the Letters of Credit Outstanding; and
(iii) third, any surplus then remaining shall be paid to the applicable Credit Parties or their successors or assigns or to whomsoever may be lawfully entitled to receive the same or as a court of competent jurisdiction may direct; provided that any amount applied to Cash Collateralize any Letters of Credit Outstanding that has not been applied to reimburse the Borrower for Unpaid Drawings under the applicable Letters of Credit at the time of expiration of all such Letters of Credit shall be applied by the Administrative Agent in the order specified in clauses (i) through (iii) above. Notwithstanding the foregoing, amounts received from any Guarantor that is not an “Eligible Contract Participant” (as defined in the Commodity Exchange Act) shall not be applied to its Obligations that are Excluded Swap Obligations.
Definitions Interpretation and Accounting Terms Defined Terms 1 Section 1.2 Computation of Time Periods 17 Section 1.3 Accounting Terms and Principles 18 Section 1.4 Conversion of Foreign Currencies 18 Section 1.5 Certain Terms 18
