issue a Change Order Sample Clauses

issue a Change Order. Any adjustment in the Contract price shall be computed in accordance with the provisions of Subsection 103.08 of this Contract. Failure of the parties to agree to an adjustment shall not excuse the Contractor from proceeding with the Contract as changed, provided the County promptly and duly makes provisional adjustments in payment or time for performance as may be reasonable. By proceeding with the required Services under protest, the Contractor shall not be deemed to have prejudiced any claim for additional compensation, or an extension of the time for completion. No action, conduct, omission, prior failure or course of dealing by the County shall act to waive, modify, change or alter the requirement that Contract Modifications must be in writing and signed by the County and the Contractor. Contractor further acknowledges that Change Orders and Contract Modifications are the exclusive method for effecting any change to the Contract. No change to this Contract is effective unless it is in writing and references this Contract. If the change is a Contract Modification, it must be signed and acknowledged by duly authorized representatives of both parties. If the change is a Change Order, it must be signed by an authorized representative of the County.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
issue a Change Order. 22.06 Any adjustment in the Contract price shall be computed in the manner as the parties may agree. Failure of the parties to agree to an adjustment shall not excuse the Contractor from proceeding with the Contract as changed, provided DWIHN promptly and duly makes provisional adjustments in payment or time for performance as may be reasonable. By proceeding with the required Services under protest, the Contractor shall not be deemed to have prejudiced any claim for additional compensation, or an extension of the time for completion.
Sample 1
issue a Change Order. Any adjustment in the Contract price shall be computed in accordance with the provisions of Subsection 103.08 of this Contract. Failure of the parties to agree to an adjustment shall not excuse the Contractor from proceeding with the Contract as changed, provided the County promptly and duly makes provisional adjustments in payment or time for performance as may be reasonable. By proceeding with the required Services under protest, the Contractor shall not be deemed to have prejudiced any claim for additional compensation, or an extension of the time for completion. No action, conduct, omission, prior failure or course of dealing by the County shall act to waive, modify, change or alter the requirement that Contract Modifications must be in writing and signed by the County and the Contractor. Contractor further acknowledges that Change Orders and Contract Modifications are the exclusive method for effecting any change to the Contract. No change to this Contract is effective unless it is in writing and references this Contract. If the change is a Contract Modification, it must be signed and acknowledged by duly authorized representatives of both parties. If the change is a Change Order, it must be signed by an authorized representative of the County. 103.08 Pricing Adjustments‌ Any adjustment in the Contract price as a result of County's exercise of its rights pursuant to Subsections 103.04, titled “Changes (Increased or Decreased Quantities)”, 103.05, titled “Modifications”, and 103.06 titled, “Alteration in Character of the Work” of this Contract shall be made in one or more of the following ways:
Sample 1

Related to issue a Change Order

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Effect of GMP Change Order The Preconstruction Phase cannot extend beyond the execution of the GMP Change Order. By definition, all services provided after the execution of the GMP Change Order are Construction Phase Services and are included in the GMP.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.

  • The Change Order The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.

  • Sole Source as Grounds for Rejection of a Change Order If a Change Order is submitted to Contractor for the purposes of adding a Bulletin to this Contract and said Bulletin designates a Sole Source from which Contractor is required to procure goods or services necessary to perform the Work, which Sole Source has not been designated previously, Contractor shall be entitled to reject the proposed Change Order if the designated Sole Source refuses to provide to Contractor the warranties, bonds, terms or schedule required under the Contract Documents, including any warranty or terms or schedule required by Bulletins referenced in the proposed Change Order. In such event, Contractor shall give written notice to the Owner rejecting the proposed Change Order and, if possible, shall accompany said written notice with a proposal from Contractor for changes or modifications to the Bulletin so as to eliminate the Sole Source designation but to achieve goods or services equal in quality or function. The Owner may then require the Design Professional to revise the subject Bulletin so as to eliminate the designation of the Sole Source by incorporation of Contractor's proposal or otherwise. Upon revision of the Bulletin by the Design Professional and approval thereof by the Owner, the Owner shall again submit to the Contractor a proposed Change Order for the purpose of adding the revised Bulletin to this Contract. If the Owner decides to retain the Sole Source in the Change Order and Contractor cannot acquire the full contractually required warranties from the Sole Source, Contractor shall be held only to the warranty terms and schedule obtainable from the Sole Source.

  • Change Order Formats Formats for Lump Sum Change Orders and for Change Orders based upon either a force account or upon unit pricing with an indeterminate number of units are in Section 7, Forms.

  • Other Change Orders For Change Orders involving the following situations that would materially affect the completion of the Work by lengthening the critical path of the Construction Progress Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.

  • Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.

Time is Money Join Law Insider Premium to draft better contracts faster.