Joint Redeveloper and City Contingencies. It is understood and agreed that the Redeveloper and City shall not be obligated to proceed with Closing until the following conditions have been satisfied or waived by both the Redeveloper and City:
Joint Redeveloper and City Contingencies Sample Clauses
Related to Joint Redeveloper and City Contingencies
Construction Contingency The proposed GMP Change Order shall include, as a separately identified item, a Construction Contingency sum in an initial amount (subject to increase or decrease) against which Design-Builder can draw at its election for the purposes set forth in Section 4 Part 4. The initial Construction Contingency sum shall include the contingency amounts stated in all accepted Component Change Orders.
COMMITMENTS AND CONTINGENCIES As of June 30, 2015, future minimum net payments under all operating leases are as follows (in thousands): Six months ending December 31, 2015 $ 87 $ 24 $ 111 Years ending December 31, 2017 — — — Total minimum net payments $ 87 $ 24 $ 111 Less: amount representing interest — Present value of net minimum payments 111 Less: current portion (111 ) Long-term portion of capital lease obligations $ — In August 2009, the Company entered into an agreement to sublease office space for its headquarters in San Francisco, California, under an operating lease that commenced in November 2009 and expires on December 30, 2014. In July 2012, the Company entered into an agreement to sublease this subleased office space under terms generally equivalent to its existing commitment for a term that commenced in August 2012 and expires in December 2014. In August 2013, the Company leased office space of approximately 2,341 square feet for its corporate office in San Francisco, California under a five year lease that commenced in September 2014 and expires on August 31, 2018. On October 15, 2014, the Company terminated this lease, closed the office and was released from all obligations under this lease. The Company leases office space in Los Angeles, California of approximately of 4,803 square feet. The lease expires in August 2015. The Company entered into a 30-month operating lease agreement for various network operating equipment beginning in the fourth quarter of 2013. Rent expense under all operating leases was not significant for each of the three months ended June 30, 2015 and 2014, respectively.
Management of REO Property (a) Prior to the acquisition by it of title to a Mortgaged Property (other than a Mortgaged Property that secures an Outside Serviced Loan Combination), the Special Servicer shall review the operation of such Mortgaged Property and determine the nature of the income that would be derived from such property if it were acquired by the Trust Fund. If the Special Servicer determines from such review that: (i) None of the income from Directly Operating such Mortgaged Property would be subject to tax as "net income from foreclosure property" within the meaning of the REMIC Provisions or would be subject to the tax imposed on "prohibited transactions" under Section 860F of the Code (either such tax referred to herein as an "REO Tax"), then such Mortgaged Property may be Directly Operated by the Special Servicer as REO Property; (ii) Directly Operating such Mortgaged Property as REO Property could result in income from such property that would be subject to an REO Tax, but that a lease of such property to another party to operate such property, or the performance of some services by an Independent Contractor with respect to such property, or another method of operating such property would not result in income subject to an REO Tax, then the Special Servicer may (provided that in the good faith and reasonable judgment of the Special Servicer, it is commercially reasonable) acquire such Mortgaged Property as REO Property and so lease or operate such REO Property; or (iii) It is reasonable to believe that Directly Operating such property as REO Property could result in income subject to an REO Tax and that no commercially reasonable means exists to operate such property as REO Property without the Trust Fund incurring or possibly incurring an REO Tax on income from such property, the Special Servicer shall deliver to the Tax Administrator, in writing, a proposed plan (the "Proposed Plan") to manage such property as REO Property. Such plan shall include potential sources of income, and, to the extent reasonably possible, estimates of the amount of income from each such source. Upon request of the Special Servicer, the Tax Administrator shall advise the Special Servicer of the Tax Administrator's federal income tax reporting position with respect to the various sources of income that the Trust Fund would derive under the Proposed Plan. After receiving the information described in the preceding sentence from the Tax Administrator, the Special Servicer shall implement the Proposed Plan (after acquiring the respective Mortgaged Property as REO Property), with any amendments required to be made thereto as a result of the Tax Administrator's tax reporting position. The Special Servicer's decision as to how each Administered REO Property shall be managed and operated shall be based on the Servicing Standard and, further, based on the good faith and reasonable judgment of the Special Servicer as to which means would be in the best interest of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)), as a collective whole, by maximizing (to the extent commercially reasonable and consistent with Section 3.17(b)) the net after-tax REO Revenues received with respect to such property without materially impairing the Special Servicer's ability to promptly sell such property for a fair price. In connection with performing their respective duties under this Section 3.17(a), both the Special Servicer and the Tax Administrator may consult with counsel and tax accountants, the reasonable cost of which consultation shall be covered by, and be reimbursable as, a Servicing Advance to be made by the Special Servicer. (b) If title to any Administered REO Property is acquired, the Special Servicer shall manage, conserve, protect and operate such REO Property for the benefit of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) solely for the purpose of its prompt disposition and sale in a manner that does not and will not: (i) cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code; or (ii) except as contemplated by Section 3.17(a), either result in the receipt by any REMIC Pool of any "income from non-permitted assets" within the meaning of Section 860F(a)(2)(B) of the Code or result in an Adverse REMIC Event or an Adverse Grantor Trust Event. Subject to the foregoing, however, the Special Servicer shall have full power and authority to do any and all things in connection therewith as are consistent with the Servicing Standard and, consistent therewith, shall withdraw from the related REO Account, to the extent of amounts on deposit therein with respect to any Administered REO Property, funds necessary for the proper operation, management, maintenance and disposition of such REO Property, including: (i) all insurance premiums due and payable in respect of such REO Property; (ii) all real estate taxes and assessments in respect of such REO Property that may result in the imposition of a lien thereon; (iii) any ground rents in respect of such REO Property; and (iv) all costs and expenses necessary to maintain, lease, sell, protect, manage, operate and restore such REO Property. To the extent that amounts on deposit in the related REO Account in respect of any Administered REO Property are insufficient for the purposes set forth in the preceding sentence with respect to such REO Property, the Master Servicer shall, at the direction of the Special Servicer, make Servicing Advances in such amounts as are necessary for such purposes unless the Master Servicer determines, in accordance with the Servicing Standard, that such payment would be a Nonrecoverable Advance; provided, however, that the Master Servicer may make any such Servicing Advance without regard to recoverability if it is a necessary fee or expense incurred in connection with the defense or prosecution of legal proceedings. (c) Without limiting the generality of the foregoing, the Special Servicer shall not, with respect to any Administered REO Property: (i) enter into, renew or extend any New Lease with respect to such Administered REO Property, if the New Lease, by its terms would give rise to any income that does not constitute Rents from Real Property; (ii) permit any amount to be received or accrued under any New Lease other than amounts that will constitute Rents from Real Property; (iii) authorize or permit any construction on such Administered REO Property, other than the completion of a building or other improvement thereon, and then only if more than 10% of the construction of such building or other improvement was completed before default on the related Serviced Mortgage Loan became imminent, all within the meaning of Section 856(e)(4)(B) of the Code; or (iv) Directly Operate, or allow any other Person, other than an Independent Contractor, to Directly Operate such Administered REO Property on any date more than 90 days after the related REO Acquisition; unless, in any such case, the Special Servicer has obtained an Opinion of Counsel (the cost of which shall be paid by the Master Servicer, at the direction of the Special Servicer, and shall be reimbursable as a Servicing Advance) to the effect that such action would not cause such Administered REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code at any time that it is held by a REMIC Pool, in which case the Special Servicer may take such actions as are specified in such Opinion of Counsel. (d) The Special Servicer may contract with any Independent Contractor for the operation and management of any Administered REO Property; provided that: (i) the terms and conditions of any such contract shall not be inconsistent herewith and shall reflect an agreement reached at arm's length; (ii) the fees of such Independent Contractor (which shall be expenses of the Trust Fund and, in the case of any Administered REO Property that relates to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) shall be reasonable and customary in consideration of the nature and locality of such Administered REO Property; (iii) except as permitted under Section 3.17(a), any such contract shall require, or shall be administered to require, that the Independent Contractor, in a timely manner, (A) pay out of related REO Revenues all costs and expenses incurred in connection with the operation and management of such Administered REO Property, including those listed in Section 3.17(b) above, and (B) except to the extent that such revenues are derived from any services rendered by the Independent Contractor to tenants of such Administered REO Property that are not customarily furnished or rendered in connection with the rental of real property (within the meaning of Section 1.856-4(b)(5) of the Treasury regulations or any successor provision), remit all related revenues collected (net of its fees and such costs and expenses) to the Special Servicer upon receipt; (iv) none of the provisions of this Section 3.17(d) relating to any such contract or to actions taken through any such Independent Contractor shall be deemed to relieve the Special Servicer of any of its duties and obligations hereunder with respect to the operation and management of such Administered REO Property; and (v) the Special Servicer shall be obligated with respect thereto to the same extent as if it alone were performing all duties and obligations in connection with the operation and management of such Administered REO Property. The Special Servicer shall be entitled to enter into any agreement with any Independent Contractor performing services for it related to its duties and obligations under Section 3.16 and this Section 3.17 for indemnification of the Special Servicer by any such Independent Contractor, and nothing in this Agreement shall be deemed to limit or modify such indemnification. No agreement entered into pursuant to this Section 3.17(d) shall be deemed a Sub-Servicing Agreement for purposes of Section 3.22. (e) Notwithstanding anything to the contrary, this Section 3.17 shall not apply to any Outside Administered REO Property.
Generating Facility The Interconnection Customer’s device for the production of electricity identified in the Interconnection Request, but shall not include the Interconnection Customer’s Interconnection Facilities.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
FUNDING CONTINGENCY a. In the event funding from state, federal, or other sources is withdrawn, reduced, or limited in any way after the effective date of this Contract and prior to completion of the work in this Contract, DCYF may: (1) Terminate this Contract with ten (10) days advance notice. If this Contract is terminated, the parties shall be liable only for performance rendered or costs incurred in accordance with the terms of this Contract prior to the effective date of termination; (2) Renegotiate the terms of the Contract under the new funding limitations and conditions; (3) After a review of project expenditures and deliverable status, extend the end date of this Contract and postpone deliverables or portions of deliverables; or (4) Pursue such other alternatives as the parties mutually agree to in writing. b. Any termination under this Section (FUNDING CONTINGENCY) shall be considered a Termination for Convenience.
Financing Contingency The Buyer’s obligations herein are contingent on the Buyer’s obtaining financing to pay the balance on the Purchase Price. The Buyer must present to the Seller a binding commitment for financing the purchase of the Property within days from the Effective date. The terms of the financing must be acceptable to and approved by the Buyer who shall not unreasonably withhold such approval. In the event that the Buyer fails to obtain financing within the time allotted, this Agreement shall automatically terminated and all funds paid by the Buyer shall be returned to the Buyer after deducting all reasonable costs incurred by the Seller in good faith in relation this Agreement.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
