Landlord’s Approval Tenant shall not make, or allow to be made, any alterations, physical additions, improvements or partitions, including without limitation the attachment of any fixtures or equipment, in, about or to the Premises (“Alterations”) without obtaining the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed with respect to proposed Alterations which: (i) comply with all Applicable Laws; (ii) are, in Landlord’s opinion, compatible with the Building or the Project and the Base Building Systems , and will not cause the Building or Project or Base Building Systems to be required to be modified to comply with any Applicable Laws (including, without limitation, the Americans With Disabilities Act); and (iii) will not unreasonably interfere with or materially disturb the use and occupancy of any other portion of the Building or Project by any other tenant or its invitees. Specifically, but without limiting the generality of the foregoing, Landlord shall have the right to approve all plans and specifications for the proposed Alterations, construction means and methods, all appropriate permits and licenses, any contractor or subcontractor to be employed on the work of Alterations, and the time for performance of such work, and may impose reasonable rules and regulations for contractors and subcontractors performing such work. Landlord may, in its sole discretion, specify engineers, general contractors, subcontractors, and architects to perform work affecting the Base Building Systems. Tenant shall also supply to Landlord any documents and information reasonably requested by Landlord in connection with Landlord’s consideration of a request for approval hereunder. No review or consent by Landlord of or to any proposed Alteration or additional work shall constitute a waiver of Tenant’s obligations under this Paragraph 12, nor constitute any warranty or representation that the same complies with all Applicable Laws, for which Tenant shall at all times be solely responsible. Tenant shall reimburse Landlord for all out-of-pocket, reasonable costs which Landlord may incur in connection with granting approval to Tenant for any such Alterations, including any costs or expenses which Landlord may incur in electing to have outside architects and engineers review said plans and specifications. Tenant shall also pay to Landlord a fee for its review of plans and its management and supervision of the progress of the work in an amount equal to three percent (3%) of the cost of any Alterations (other than for Minor Alterations). The Tenant Improvements constructed pursuant to the Tenant Improvement Agreement shall not be deemed to be Alterations hereunder.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Removal of Alterations If Tenant fails to remove by the expiration or earlier termination of this Lease all of its personal property, or any Alterations identified by Landlord for removal, Landlord may, at its option, treat such failure as a hold-over pursuant to Subparagraph 11(b) above, and/or Landlord may (without liability to Tenant for loss thereof) treat such personal property and/or Alterations as abandoned and, at Tenant's sole cost and expense, and in addition to Landlord's other rights and remedies under this Lease, at law or in equity: (a) remove and store such items; and/or (b) upon ten (10) days prior notice to Tenant, sell, discard or otherwise dispose of all or any such items at private or public sale for such price as Landlord may obtain or by other commercially reasonable means. Tenant shall be liable for all costs of disposition of Tenant's abandoned property and Landlord shall have no liability to Tenant with respect to any such abandoned property. Landlord agrees to apply the proceeds of any sale of any such property to any amounts due to Landlord under this Lease from Tenant (including Landlord's attorneys' fees and other costs incurred in the removal, storage and/or sale of such items), with any remainder to be paid to Tenant.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
Removal of Improvements Grantor shall not demolish or remove any Improvements from the Real Property without Lender's prior written consent. As a condition to the removal of any Improvements, Lender may require Grantor to make arrangements satisfactory to Lender to replace such Improvements with Improvements of at least equal value.
ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Landlord Approval (Check one)
Landlord’s Consent Landlord shall not unreasonably withhold or delay its consent to any proposed Transfer of the Subject Space to the Transferee on the terms specified in the Transfer Notice. Without limitation as to other reasonable grounds for withholding consent, the parties hereby agree that it shall be reasonable under this Lease and under any applicable law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply:
14.2.1 The Transferee is of a character or reputation or engaged in a business which is not consistent with the quality of the Building or the Project;
14.2.2 The Transferee is either a governmental agency or instrumentality thereof;
14.2.3 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the responsibilities to be undertaken in connection with the Transfer on the date consent is requested; or
14.2.4 The proposed Transfer would cause a violation of another lease for space in the Project, or would give an occupant of the Project a right to cancel its lease. If Landlord consents to any Transfer pursuant to the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 of this Lease), Tenant may within six (6) months after Landlord’s consent, but not later than the expiration of said six-month period, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 of this Lease, provided that if there are any changes in the terms and conditions from those specified in the Transfer Notice such that Landlord would initially have been entitled to refuse its consent to such Transfer under this Section 14.2, Tenant shall again submit the Transfer to Landlord for its approval and other action under this Article 14 (including Landlord’s right of recapture, if any, under Section 14.4 of this Lease). Notwithstanding anything to the contrary in this Lease, if Tenant or any proposed Transferee claims that Landlord has unreasonably withheld or delayed its consent under Section 14.2 or otherwise has breached or acted unreasonably under this Article 14, their sole remedies shall be a suit for contract damages (other than damages for injury to, or interference with, Tenant’s business including, without limitation, loss of profits, however occurring) or declaratory judgment and an injunction for the relief sought, and Tenant hereby waives all other remedies, including, without limitation, any right at law or equity to terminate this Lease, on its own behalf and, to the extent permitted under all applicable laws, on behalf of the proposed Transferee.
Improvements and Alterations (a) The Lessee, at the Lessee’s own cost and expense, (i) shall make alterations, renovations, repairs, improvements and additions to the Leased Property or any part thereof and substitutions and replacements therefor (collectively, “Alterations”) which are (A) necessary to repair or maintain the Improvements or the Site in the condition required by Section 9.1 or (B) necessary or advisable to restore the Improvements and the Site to its condition existing prior to a Casualty or Condemnation to the extent required pursuant to Article XIII, and (ii) so long as no Material Default or Event of Default has occurred and is continuing, may undertake Alterations on the Leased Property so long as such Alterations comply in all material respects with Applicable Laws and are consistent and comply with Section 9.1 and subsection (b) of this Section 9.2.
(b) The making of any Alterations pursuant to subsection (a)(i) above of this Section 9.2 must be in compliance with the following requirements: The Lessee shall not make any Alterations in violation of the terms of any restriction, easement, condition, covenant or other similar matter affecting title to or binding on the Improvements or the Site.
(i) No Alterations shall be undertaken until the Lessee shall have procured and paid for, so far as the same may be required from time to time, all permits and authorizations relating to such Alterations of all municipal and other Authorities having jurisdiction over the Improvements or the Site. Lessor, at the Lessee’s expense, shall join in the application for any such permit or authorization and execute and deliver any document in connection therewith, whenever such joinder is necessary or advisable; provided that, however, such joinder shall not constitute or be deemed to constitute, any assumption or responsibility or liability whatsoever.
(ii) The Alterations shall be completed in a good and workmanlike manner and in compliance in all material respects with all Applicable Laws then in effect and with the Insurance Requirements.
(iii) All Alterations shall, when completed, be of such a character as to not materially diminish (A) the utility of the Improvements as a corporate office complex including a corporate office building and any uses ancillary thereto, (B) the then current Fair Market Value as determined by reference to the Appraisal, or (C) the Fair Market Value as determined by reference to the Appraisal as of the scheduled expiration date of the Lease Term.
(iv) The Lessee shall have made adequate arrangements for payment of the cost of all Alterations when due so that the Improvements and the Site shall at all times be free of Liens for labor and materials supplied or claimed to have been supplied to the Improvements or the Site, other than Permitted Liens; provided, that the Lessee shall have the right to engage in Permitted Contests in accordance with Section 9.5.
(v) The Alterations must be located solely on the Site.
