Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Landlord’s Remedies If an Event of Tenant’s Default occurs, Landlord shall have the following remedies, in addition to all other rights and remedies provided by any Law or otherwise provided in this Lease, to which Landlord may resort cumulatively or in the alternative:
Landlord Delay As used herein, (x) “Force Majeure Construction Delay” shall mean acts of God, casualties, natural disasters, strikes, war, terrorist attacks, lockouts, labor disputes or civil commotion, and (y) “Landlord Delay” shall mean a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Landlord’s Right to Cure Tenant’s Default If an Event of Default shall have occurred and be continuing, Landlord, after Notice to Tenant (which Notice shall not be required if Landlord shall reasonably determine immediate action is necessary to protect person or property), without waiving or releasing any obligation of Tenant and without waiving or releasing any Event of Default, may (but shall not be obligated to), at any time thereafter, make such payment or perform such act for the account and at the expense of Tenant, and may, to the maximum extent permitted by law, enter upon the Leased Property or any portion thereof for such purpose and take all such action thereon as, in Landlord's sole and absolute discretion, may be necessary or appropriate therefor. No such entry shall be deemed an eviction of Tenant. All reasonable costs and expenses (including, without limitation, reasonable attorneys' fees) incurred by Landlord in connection therewith, together with interest thereon (to the extent permitted by law) at the Overdue Rate from the date such sums are paid by Landlord until repaid, shall be paid by Tenant to Landlord, on demand.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.
Landlord Repairs Notwithstanding anything contrary herein, Landlord shall repair, replace and restore the foundation, exterior and interior load-bearing walls, roof structure and roof covering and tuckpointing of the Property; provided, however, that (i) all costs and expenses so incurred by Landlord to repair, replace and restore the above items shall constitute Operating Expenses; provided, however, that with respect to any costs incurred in the replacement context, those costs shall not constitute an Operating Expense except to the extent that such costs so qualify under SECTION 3.1.1(vii); and (ii) notwithstanding (i) above, in the event that any such repair, replacement or restoration is necessitated by any or all of the matters set forth in SECTIONS 13.1(a) through (d) above (collectively, "TENANT NECESSITATED REPAIRS"), then Tenant shall be required to reimburse Landlord for all costs and expenses that Landlord incurs in order to perform such Tenant Necessitated Repairs, and such reimbursement shall be paid, in full, within 10 days after Landlord's delivery of demand therefor. Landlord agrees to commence the repairs, replacements or restoration described in this SECTION 13.2 within a reasonable period of time after receiving from Tenant written notice of the need for such repairs.
Landlord Remedies The remedies provided Landlord under this Lease are cumulative. Upon the occurrence of any default by Tenant, and in addition to any and all other rights provided a landlord under law or equity for breach of a lease or tenancy by a tenant, Landlord shall have the right to pursue one or more of the following remedies:
