Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.
Tenant Except as otherwise expressly required of Landlord, Tenant shall, at Tenant’s expense, keep and maintain the Premises, including but not limited to all entry doors, damage to entry doors occasioned by theft or vandalism, furnishings, lighting, trade fixtures, above-ground plumbing and conduits beginning at the point of entry into the Premises, windows, glass and plate glass, doors, interior walls and finish work, floor surfaces and floor coverings, sprinkler and fire protection systems (which shall be in good working order as of the Commencement Date and in compliance with all Applicable Laws), and routine maintenance and repairs of the HVAC System (together with replacement of the HVAC System exclusively 23134410.6 servicing the Premises and installed by Tenant), in good and sanitary condition and repair and in compliance with all Applicable Laws. Tenant shall permit no waste, except normal wear and tear. Tenant shall also be responsible for arranging janitorial services for the Premises and the cost thereof. Tenant shall promptly notify Landlord, in writing, of any known defective condition which Landlord is required to repair, and failure to so report such known defects in a commercially reasonable time and manner shall make Tenant responsible to Landlord for any increased liability incurred by Landlord by reason of such failure to report the known defective condition. Any contractor selected by Tenant in connection with the performance of Tenant’s obligations under this Section in or about the Premises or the Building shall require prior written approval of the Landlord which approval shall not be unreasonably withheld, conditioned or delayed, such approval shall require, at a minimum, Lxxxxxxx’s receipt of a Certificate of General Liability Insurance adding the Agent and the Landlord as additionally insured, proof that the contractor is duly licensed and permitted in the municipality where the Premises is located, to the extent such licensing and permitting is required by such municipality, acknowledgment and agreement by the contractor that all work shall be done with good workmanship and in accordance with current building codes and ordinances, and with agreement to adhere to any other reasonable standards imposed by Landlord for the protection and preservation of the Building and Premises.
The Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises set forth in Section 2.2 of the Summary (the “Premises”). The outline of the Premises is set forth in Exhibit A attached hereto. The outline of the “Building” and the “Project,” as those terms are defined in Section 1.1.2 below, are further depicted on the Site Plan attached hereto as Exhibit A. The parties hereto agree that the lease of the Premises is upon and subject to the terms, covenants and conditions herein set forth, and Tenant covenants as a material part of the consideration for this Lease to keep and perform each and all of such terms, covenants and conditions by it to be kept and performed. The parties hereto hereby acknowledge that the purpose of Exhibit A is to show the approximate location of the Premises only, and such Exhibit is not meant to constitute an agreement, representation or warranty as to the construction of the Premises, the precise area thereof or the specific location of the “Common Areas,” as that term is defined in Section 1.1.3, below, or the elements thereof or of the accessways to the Premises or the “Project,” as that term is defined in Section 1.1.2, below, and that the square footage of the Premises shall be as set forth in Section 2.1 of the Summary of Basic Lease Information. Except as specifically set forth in this Lease and in the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”), Landlord shall not be obligated to provide or pay for any improvement work or services related to the improvement of the Premises. Xxxxxx also acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty regarding the condition of the Premises, the Building or the Project or with respect to the suitability of any of the foregoing for the conduct of Xxxxxx’s business, except as specifically set forth in this Lease and the Tenant Work Letter. For purposes of Section 1938 of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges, that the Building and Premises have not undergone inspection by a Certified Access Specialist (CASp). Landlord shall deliver the Premises to Tenant in good, vacant, broom clean condition, in compliance with all laws, with the roof water-tight and shall cause the plumbing, electrical systems, fire sprinkler system, lighting, and all other building systems serving the Premises in good operating condition and repair on or before the Lease Commencement Date, or such earlier date as Landlord and Tenant mutually agree. Landlord will be responsible for causing the exterior of the Building, the existing Building entrances, and all exterior Common Areas (including required striping and handicapped spaces in the parking areas) to be in compliance with ADA and parking requirements, to the extent required to allow the legal occupancy of the Premises or completion of the Tenant Improvements.
Subleased Premises Sublandlord hereby subleases to Subtenant and Subtenant hereby subleases from Sublandlord for the term, at the rental, and upon all of the conditions set forth herein, the Subleased Premises.
Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Landlord’s Entry Landlord and its authorized representatives may at all reasonable times and upon reasonable notice to Tenant enter the Premises to: (a) inspect the Premises; (b) exercise and perform Landlord's rights and obligations under this Lease; (c) post notices of non-responsibility or other protective notices available under the Laws; (d) show the Premises to current or prospective mortgagees, or to prospective purchasers of the Property; or (e) during the last 12 months of the Term, show the Premises to prospective tenants. Landlord, in the event of any emergency, may enter the Premises at any time without notice to Tenant. If Landlord receives prior written notification from Tenant that specified areas within the Premises contain confidential materials, then Landlord shall not enter such portions of the Premises unless accompanied by a representative of Tenant except (i) in case of an emergency, or (ii) if Tenant authorizes Landlord to enter such portions of the Premises without accompaniment of Tenant's representative. Landlord's entry into the Premises is not to be construed as a forcible or unlawful entry into, or detainer of, the Premises or as an eviction of Tenant from all or any part of the Premises. Subject to Section 9.3 below, Tenant will also permit Landlord (or its designees) to erect, install, use, maintain, replace and repair pipes, cables, conduits, plumbing and vents, and telephone, electric and other wires or other items, in, to and through the Premises if Landlord reasonably determines that such activities are necessary for properly operating and maintaining the Building.
Leased Premises Lessor hereby leases to Lessee, and Lessee leases and takes from Lessor, the Leased Premises subject to the conditions of this Lease.
Demised Premises 2.01. Landlord leases to Tenant and Tenant leases from Landlord certain office space (hereinafter called the "Demised Premises") in a nine-story office building currently being renovated (the "Building") situated on certain land more particularly described by metes and bounds in Exhibit A attached hereto (the "Land") leased by Landlord at 0000 Xxx Xxxxx Xxxx in Raleigh, North Carolina. The Demised Premises consists of the square feet of rentable area in the Building disclosed on Schedule I attached to this Lease and made a part hereof (hereinafter called "Schedule I"), all of said space being shown on Exhibit B attached hereto. All calculations of the rentable area of the Demised Premises and the Building shall be made in accordance with the BOMA Standard of Measuring Floor Area of Office Buildings (reprinted in August, 1990). Rentable square feet for any tenant space which constitutes all of the available office space on any floor in the Building shall be as set forth in Exhibit X-x attached hereto. Landlord, at its expense, shall provide Tenant with the Base Building items set forth on Exhibit C-l 2.02. The Demised Premises consist of the unfinished interior office space in the Building. Landlord, at its expense, shall provide Tenant with the "Base Building" items set forth on Exhibit C-l. Landlord, at Tenant's cost, shall also install the items and perform the work (collectively "upfitting") specified in the plans and upfitting requirements set forth in Exhibit C; however, Landlord shall provide Tenant with an upfitting allowance to subsidize Tenant's upfitting cost as specified in Schedule I. All work shall be performed in accordance with the provisions of Article XVI 2.03. Prior to occupancy of the Demised Premises by the Tenant, Landlord and Tenant shall enter into a supplement of this Lease in the forth attached hereto as Exhibit D setting forth the exact measurements of the Demised Premises calculated as provided hereinabove, the Commencement Date and Expiration Date of the term of this Lease as provided in Article IV and the exact amount of the Annual Minimum Rent (hereinafter defined) and monthly installments of minimum rent required in accordance with Article V herein, with such terms, conditions and provisions being consistent with the terms set forth in this Lease as of the date hereof. 2.04. Exhibits A, B, X-x, C, X-x and D and Schedule I mentioned above and Exhibit E mentioned hereafter are attached hereto and incorporated herein by this reference.