We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Lessee Insurance Default Sample Clauses

Lessee Insurance Default 

Related to Lessee Insurance Default

  • Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.

  • Tenant’s Default 14.1 Any other provisions in this Lease notwithstanding, it shall be an event of default (“Event of Default”) under this Lease if: (i) Tenant fails to pay any installment of rent or any other sum payable by Tenant hereunder when due and such failure continues for a period of ten (10) days after written notice from Landlord to Tenant that such payment has not been received, or (ii) Tenant fails to observe or perform any other material covenant or agreement of Tenant herein contained and such failure continues after written notice given by or on behalf of Landlord to Tenant for more than thirty (30) days, provided, however, that if such non-monetary Event of Default by Tenant cannot reasonably be cured within such thirty (30) day period, and provided further that Tenant is proceeding with due diligence to effect a cure of said Event of Default, no Event of Default hereunder shall be declared by Landlord if Tenant continues to proceed with diligence to cure said Event of Default, but in no event shall such cure period extend beyond ninety (90) days following notice from Landlord of such violation, default or breach, or (iii) Tenant files a petition commencing a voluntary case, or has filed against it a petition commencing an involuntary case, under the Federal Bankruptcy Code (Title 11 of the United States Code), as now or hereafter in effect, or under any similar law, or files or has filed against it a petition or answer in bankruptcy or for reorganization or for an arrangement pursuant to any state bankruptcy law or any similar state law, and, in the case of any such involuntary action, such action shall not be dismissed, discharged or denied within sixty (60) days after the filing thereof, or Tenant consents or acquiesces in the filing thereof, or (iv) a custodian, receiver, trustee or liquidator of Tenant or of all or substantially all of Tenant’s property or of the Premises shall be appointed in any proceedings brought by or against Tenant and, in the latter case, such entity shall not be discharged within sixty (60) days after such appointment or Tenant consents to or acquiesces in such appointment, or (v) Tenant shall generally not pay Tenant’s debts as such debts become due, or shall make an assignment for the benefit of creditors, or shall admit in writing its inability to pay its debts generally as they become due. The notice and grace period provisions in clauses (i) and (ii) above shall have no application to the Events of Default referred to in clauses (iii) through (v) above. 14.2 If Tenant shall fail to make any payment of rent when due or if Tenant shall fail to keep and perform any express written covenant of this Lease and shall continue in default for a period of ten (10) days after Tenant has received written notice of such default and demand of performance from Landlord, Landlord may commence judicial proceedings, provided, however, if any default shall occur (other than in the payment of rent) which cannot be cured within a period of thirty (30) days and Tenant, prior to the expiration of thirty (30) days from and after the giving of notice as aforesaid, commences to eliminate such default and proceeds diligently to take steps to cure the same, Landlord shall not have the right to declare the term ended by reason thereof for an additional period of sixty (60) days. 14.3 In the event of any such Event of Default, Landlord at any time thereafter may at its option exercise any remedies available to Landlord at law or in equity, including, without limitation, one or more of the following remedies:

  • Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.

  • Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.

  • LESSEE'S DEFAULT (i) If Lessee shall default in the payment of the Fixed Annual Rent, any additional rent or any other sums payable by Lessee herein when due, and such default shall continue for a period of five (5) days after written notice, or (ii) if Lessee shall default in the performance of any nonmonetary covenants or agreements of this Lease and said default shall continue for twenty (20) days after written notice thereof, or in the event that the default be of such a nature as cannot with diligent effort be cured within said twenty (20) day period, if Lessee shall not commence to cure within said period and diligently prosecute remedial efforts to completion within a reasonable time thereafter, not to exceed sixty (60) (iii) if Lessee should become bankrupt or insolvent or any debtor proceedings be taken by or against Lessee or (iv) if Lessee shall abandon or vacate the Premises prior to the expiration of the term of this Lease, then and in addition to any and all other legal remedies and rights available to Lessor at law or in equity, Lessor may: A. Declare the entire balance of fixed Annual Rent due hereunder for the remainder of the term of this Lease to be due and payable and may collect the same by distress or otherwise; B. Terminate this Lease and any right of renewal thereof, and retake possession of the Premises; C. Without terminating this Lease, re-enter and re-let the Premises, or any part thereof, with or without legal process, as the agent and for the account of Lessee, upon such terms and conditions as Lessor may deem advisable or satisfactory, in which event the rents received on such re-letting shall be applied first to the expenses of such re-letting and collection including but not limited to, necessary renovation and alterations of the Premises, reasonable attorney’s fees, any real estate commissions paid, and thereafter toward payment of all sums due or to become due Lessor hereunder, and if a sufficient sum shall not be thus realized or secured to pay such sums and other charges, (i) at Lessor’s option, Lessee shall pay Lessor any deficiency immediately upon demand therefor, notwithstanding Lessor may have received periodic rental in excess of the periodic rental stipulated in this Lease in previous or subsequent rental periods, and Lessor may bring an action therefor as such deficiency shall arise, or (ii) at Lessor’s option, the entire deficiency, which is subject to ascertainment for the remaining term of this Lease, shall be immediately due and payable by Lessee. Lessor shall use commercially reasonable efforts to re-let the Premises. Lessor shall not, in any event, be required to pay Lessee any surplus of any sums received by Lessor on a re-letting of said Premises in excess of the rent provided in this Lease. D. If any Event of Default occurs, Lessor, in addition to other rights and remedies it may have, shall have the right to remove all or any part of Lessee’s property from the Premises and any property removed may be stored in any public warehouse or elsewhere at the cost of, and for the account of Lessee and the Lessor shall not be responsible for the care or safekeeping thereof whether in transport, storage or otherwise, and Lessee hereby waives any and all claim against Lessor for loss, destruction and/or damage or injury which may be occasioned by any of the aforesaid acts. Lessee shall, upon execution of this Lease and promptly thereafter from time to time, give Lessor notice of any leased personal property brought onto the Premises. E. No such re-entry or taking possession of the Premises by Lessor shall be construed as an election on Lessor’s part to terminate this Lease unless a written notice of such intention is given to Lessee. Notwithstanding any such re-letting without termination. Lessor may at all times thereafter elect to terminate this Lease for such previous default. Any such re-entry shall be allowed by Lessee without hindrance, and Lessor shall not be liable in damages for any such re-entry, or guilty of trespass or forcible entry except for damages or injury caused by intentional misconduct. F. In the event of a breach or threatened breach of any covenant of this Lease, Lessor shall have the right of injunction. Any and all rights, remedies and options given in this Lease to Lessor shall be cumulative and in addition to and without waiver of, or in derogation of, any right or remedy given to it under any law now or hereafter in effect or in equity. G. If Lessee shall default in the performance of any provision of this Lease on Lessee’s part to be performed, Lessor may perform the same for the account of Lessee and Lessee shall promptly reimburse Lessor for any expense incurred therefor, which expenses shall be deemed to be additional rent.

  • Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.

  • Default by Lessor Lessor shall not be in default unless Lessor fails to perform obligations required of Lessor within a reasonable time, but in no event later than thirty (30) days after written notice by Lessee to Lessor and to the holder of any first mortgage or deed of trust covering the Premises whose name and address shall have theretofore been furnished to Lessee in writing, specifying wherein Lessor has failed to perform such obligation; provided, however, that if the nature of Lessor's obligation is such that more than thirty (30) days are required for performance then Lessor shall not be in default if Lessor commences performance within such 30-day period and thereafter diligently prosecutes the same to completion.

  • TENANT’S DEFAULTS A. If there is a default by Tenant under the terms of this Lease, other than the obligation to pay Rent and Additional Rent, or Tenant vacates the Office prior to the Termination Date, or if an execution has been issued against the property of Tenant or Tenant whereby the Office is used and/or occupied by someone other than Tenant, or if this Lease be rejected in a Bankruptcy proceeding, or should Tenant not take possession of the Office with thirty (30) days from the Possession Date, the Landlord, upon fifteen (15) days prior written notice to Tenant which sets forth Tenant’s default(s) and should Tenant fail to completely cure said specified default(s) within said fifteen (15) days, or if the default(s), by its nature cannot be cured within said fifteen (15) days or should Tenant fail to undertake with diligent effort to cure the default(s) within said fifteen (15) days, then , in such event, Landlord may serve upon Tenant, a written five (5) day notice canceling this Lease and Tenant, at the end of said five (5) days shall vacate and surrender the Office and Tenant shall continue to remain liable as set forth under this Lease. B. If Tenant shall be in default in the payment of Rent and/or Additional Rent, or if the notice given pursuant to “A” hereinabove has expired or if Tenant is in default in payment of any other matter for which Tenant is liable to pay, then Landlord, without notice, (the giving of notice is hereby expressly waived by Tenant), may re- enter the Office, by force or otherwise, and dispossess Tenant or other occupant, by any lawful manner, and remove their possessions and retake the Office. Tenant expressly waives the right to receive notice of such re- entry by Landlord and agrees that Landlord shall not be responsible for any damage sustained to the property of Tenant or other occupant. If their be an extension or renewal of this Lease and Tenant shall default under any term, condition and/or provision of this Lease, Landlord may cancel such renewal or extension upon three(3) days prior written notice to Tenant.

  • Lessor's Default It shall be a breach of this Lease if Lessor fails to observe or perform any term, covenant or condition of this Lease on its part to be performed and such failure continues for a period of 30 days after Notice thereof from Lessee, unless such failure cannot with due diligence be cured within a period of 30 days, in which case such failure shall not be deemed a breach if Lessor proceeds within such 30-day period, with due diligence, to cure the failure and thereafter diligently completes the curing thereof. The time within which Lessor shall be obligated to cure any such failure also shall be subject to extension of time due to the occurrence of any Unavoidable Delay. If Lessor does not cure any such failure within the applicable time period as aforesaid, Lessee may declare the existence of a "Lessor Default" by a second Notice to Lessor. Thereafter, Lessee may forthwith cure the same in accordance with the provisions of Article 32, subject to the provisions of the following paragraph. Lessee shall have no right to terminate this Lease for any Lessor Default and no right, for any such Lessor Default, to offset or counterclaim against any Rent or other charges due hereunder. If Lessor shall in good faith dispute the occurrence of any Lessor Default and Lessor, before the expiration of the applicable cure period, shall give Notice thereof to Lessee, setting forth, in reasonable detail, the basis therefor, no Lessor Default shall be deemed to have occurred and Lessor shall have no obligation with respect thereto until final adverse determination thereof, whether through arbitration or otherwise; provided, however, that in the event of any such adverse determination, Lessor shall pay to Lessee interest on any disputed funds at the Base Rate, from the date demand for such funds was made by Lessee until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. If Lessee and Lessor shall fail, in good faith, to resolve any such dispute within ten (10) days after Lessor's Notice of dispute, either may submit the matter for determination by arbitration, but only if such matter is required to be submitted to arbitration pursuant to any provision of this Lease, or otherwise by a court of competent jurisdiction.

  • Waiver of Event of Default The Majority Certificateholders may, on behalf of all Certificateholders, by notice in writing to the Trustee, direct the Trustee to waive any events permitting removal of any Master Servicer under this Agreement, provided, however, that the Majority Certificateholders may not waive an event that results in a failure to make any required distribution on a Certificate without the consent of the Holder of such Certificate. Upon any waiver of an Event of Default, such event shall cease to exist and any Event of Default arising therefrom shall be deemed to have been remedied for every purpose of this Agreement. No such waiver shall extend to any subsequent or other event or impair any right consequent thereto except to the extent expressly so waived. Notice of any such waiver shall be given by the Trustee to the Rating Agency.