LIABILITY FOR DAMAGE CAUSED BY Sample Clauses

LIABILITY FOR DAMAGE CAUSED BY. WORKS AND/OR SERVICES. The Contractor/Provider shall not be liable for material or personal damage caused by the Work(s) and/or Service(s) after receipt of the same by the Client.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
LIABILITY FOR DAMAGE CAUSED BY. THE PRODUCTS 6.1. Company shall not be liable for any damage to movable or immovable property caused by the Goods after they have been delivered. Nor shall Company be liable for any damage to products manufactured by the Customer or to products of which the Customer’s products form a part. If Company incurs liability towards any third party for such damage or loss as described above, the Customer shall indemnify, defend and hold Company harmless. 6.2. If a third party lodges a claim for loss or damage referred to in the Clause 6.2 against one of the parties, the other party shall be informed thereof in writing without delay. The Customer shall be obliged to let itself be summoned to the court or arbitral tribunal examining claims for damages lodged against Company on the basis of damage allegedly caused by the Goods. 7.
Sample 1
LIABILITY FOR DAMAGE CAUSED BY the goods When a Vendor is liable for damage or loss suffered by a third party, the Client shall re- fund the loss incurred to the Vendor if the Vendor has been exempted from the corre- sponding damage and loss caused to the Client in accordance with items (a) and (b) below. The Vendor shall not be liable for damage caused by goods after delivery of the goods where the damaged item is
Sample 1

Related to LIABILITY FOR DAMAGE CAUSED BY

  • Liability for Damage Each party shall be liable to the other for all damage to the property of the other negligently, recklessly or intentionally caused by that party (or their agents, employees or invitees), except to the extent the loss is insured and subrogation is waived under the owner's policy.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages.

  • Liability for loss or damage Subject to the provisions of the Occupiers Liability Act 1957 and the Defective Premises Act 1972, we shall not in any circumstances incur any liability in respect of loss or damage to any person or property or otherwise, unless the loss or damage was caused by our negligence.

  • Liability for other losses, damages etc Save and except as expressly provided in this Article, neither Party hereto shall be liable in any manner whatsoever to the other Party in respect of any loss, damage, cost, expense, claims, demands and proceedings relating to or arising out of occurrence or existence of any Force Majeure Event.

  • Liability for Loss If Included Timber is destroyed or damaged by an unexpected event that significantly changes the nature of Included Timber, such as fire, wind, flood, insects, disease, or similar cause, the party holding title shall bear the timber value loss resulting from such destruction or damage; except that such losses after removal of timber from Sale Area, but before Scaling, shall be borne by Purchaser at Current Contract Rates and Required Deposits. Deterioration or loss of value of salvage timber is not an unexpected event, except for deterioration due to delay or interruption that qualifies for Contract Term Adjustment or under B8.33. In the event Included Timber to which Forest Service holds title is destroyed, Purchaser will not be obligated to remove and pay for such timber. In the event Included Timber to which Forest Service holds title is damaged, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the value loss and the appraised unit value of timber after the loss. Current Contract Rates in effect at the time of the value loss shall be adjusted by differences to become the redetermined rates. There shall be no obligation for Forest Service to supply, or for Purchaser to accept and pay for, other timber in lieu of that destroyed or damaged. This Subsection shall not be construed to relieve either party of liability for negligence.

  • OUR RESPONSIBILITY FOR LOSS OR DAMAGE SUFFERED BY YOU 14.1 We are responsible to you for foreseeable loss and damage caused by us. If we fail to comply with this Agreement, we are responsible for loss or damage you suffer that is a foreseeable result of our breaking this Agreement or our failure to use reasonable care and skill, but we are not responsible for any loss or damage that is not foreseeable. Loss or damage is foreseeable if either it is obvious that it will happen, or if, at the time the Agreement is made, both we and you knew it might happen. We are not responsible for any loss or damage you suffer which is a result of you breaking this Agreement or you acting fraudulently.

  • NO LIABILITY FOR DAMAGES In no event shall the author of this Software be liable for any special, consequential, incidental or indirect damages whatsoever (including, without limitation, damages for loss of business profits, business interruption, loss of business information, or any other pecuniary loss) arising out of the use of or inability to use this product, even if the Author of this Software is aware of the possibility of such damages and known defects.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), and pursuant to its requirements only, reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the Vendor hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the bidder hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!