Limitation on Construction under Assistance Sample Clauses

Limitation on Construction under Assistance. Effective Date: 08/16/2013 The Agency’s infrastructure projects are increasingly a critical component of development programs. However, the limited management oversight the Agency can legally assert over recipients under assistance awards minimizes the Agency’s ability to ensure that the design and construction activities are carried out properly. As such, Operating Units and AOs must adhere to the Administrator-approved policy and procedures that limit the use of assistance awards to accomplish construction activities (ADS 303maw, USAID Implementation of Construction Activities). AOs must include the Mandatory Standard Provision, “Limiting Construction Activities (August 2013)” in all solicitations and awards. If the assistance award permits construction activities based on the policy above (or as authorized by waiver), the AO must insert the description and location(s) of the specific construction activities under section (d) of the provision. If the award does not include construction activities, the AO must insert “Construction is not eligible for reimbursement under this award” in section
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs

Related to Limitation on Construction under Assistance

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Limitation of Personal Liability All the parties hereto acknowledge and agree that all liabilities of the Trust arising, directly or indirectly, under this Agreement, of any and every nature whatsoever, shall be satisfied solely out of the assets of the Fund and that no Trustee, officer or holder of shares of beneficial interest of the Trust shall be personally liable for any of the foregoing liabilities. The Trust Instrument describes in detail the respective responsibilities and limitations on liability of the Trustees, officers and holders of shares of beneficial interest of the Trust.

  • Limitation on Remedies In addition to any other limitation on remedies or limitations of liability set forth in our Terms of Service or in applicable law or regulations, the Company shall not be liable for any delay or failure to provide Service at any time or from time to time, or any interruption or degradation of Service quality that is caused by any of the following: (a) an act or omission of an underlying carrier, service provider, vendor or other third party; (b) equipment, network or facility failure, including failure caused by the loss of power; (c) equipment, network or facility upgrade or modification; (d) force majeure events such as (but not limited to) acts of God, acts of nature, strikes, fire, war, riot, acts of terrorism and government actions; (e) equipment or facility shortage; (f) equipment or facility relocation; (g) any act or omission by you or any person using your Service; (h) theft, fraud or abuse of Service; or (i) any other cause that is beyond the Company’s reasonable control. THE EXTENT PERMITTED BY LAW, OUR TOTAL LIABILITY FOR ANY CLAIM UNDER THIS AGREEMENT, INCLUDING FOR ANY EXPRESS OR IMPLIED WARRANTIES, IS LIMITED TO THE AMOUNT YOU PAID US FOR THE AFFECTED SERVICE OR FACILITIES, WHETHER SUCH CLAIM OR REMEDY IS SOUGHT IN CONTRACT OR TORT, INCLUDING NEGLIGENCE, STRICT LIABILITY OR OTHERWISE. TO THE EXTENT PERMITTED BY LAW, WE SHALL NOT BE LIABLE TO YOU FOR ANY CONSEQUENTIAL, INCIDENTAL, INDIRECT, PUNITIVE, SPECIAL OR TREBLED OR ENHANCED DAMAGES, INCLUDING, BUT NOT LIMITED TO LOST PROFITS, LOST BUSINESS, OR OTHER COMMERCIAL OR ECONOMIC LOSS, WHETHER SUCH DAMAGES ARE CLAIMED FOR BREACH OF CONTRACT, NEGLIGENCE OR OTHERWISE AND WHETHER OR NOT WE HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

  • Limitation on Use of Information The Fund agrees neither to use the information received from the Intermediary for any purpose other than to comply with SEC Rule 22c-2 and other applicable laws, rules and regulations, nor to share the information with anyone other than its employees who legitimately need access to it. Neither the Fund nor any of its affiliates or subsidiaries may use any information provided pursuant to this Agreement for marketing or solicitation purposes. The Fund will take such steps as are reasonably necessary to ensure compliance with this obligation. The Fund shall indemnify and hold the Intermediaries, individually and collectively, (and any of their respective directors, officers, employees, or agents) harmless from any damages, loss, cost, or liability (including reasonable legal fees and the cost of enforcing this indemnity) arising out of or resulting from any unauthorized use of or disclosure by the Fund of the information received from the Intermediaries pursuant to this Agreement. In addition, because an award of money damages (whether pursuant to the foregoing sentence or otherwise) may be inadequate for any breach of this provision and any such breach may cause the Intermediaries irreparable harm, the Fund also agrees that, in the event of any breach or threatened breach of this provision, the Intermediaries will also be entitled, without the requirement of posting a bond or other security, to seek equitable relief, including injunctive relief and specific performance. Such remedies will not be the exclusive remedies for any breach of this provision but will be in addition to all other remedies available at law or in equity to the Intermediaries. In the event that the Fund is required by legal process, law, or regulation to disclose any information received from the Intermediaries pursuant to this Agreement, the Fund shall provide Intermediaries with prompt written notice of such requirement as far in advance of the proposed disclosure as possible so that the Intermediaries (at their expense) may either seek a protective order or other appropriate remedy which is necessary to protect their interests or waive compliance with this provision to the extent necessary.

  • Limitation on Guarantor Liability Each Guarantor, and by its acceptance of Notes, each Holder, hereby confirms that it is the intention of all such parties that the Note Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of Bankruptcy Law, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law to the extent applicable to any Note Guarantee. To effectuate the foregoing intention, the Trustee, the Holders and the Guarantors hereby irrevocably agree that the obligations of such Guarantor will be limited to the maximum amount that will, after giving effect to such maximum amount and all other contingent and fixed liabilities of such Guarantor that are relevant under such laws, and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under this Article 10, result in the obligations of such Guarantor under its Note Guarantee not constituting a fraudulent transfer or conveyance.

  • LIMITATION OF OUR LIABILITY We are not responsible or liable to you or any supplementary cardmember for: • any delay or failure by a merchant to accept the card, • goods and services you charge to your account, including any dispute with a merchant about goods and services charged to your account, • any costs, damages or expenses arising out of our failure to carry out our obligations under this agreement if that failure is caused by a third party or because of a systems failure, data processing failure, industrial dispute or other action outside our control, and • loss of profits or any incidental, indirect, consequential, punitive or special damages regardless of how they arise. For example, we will not be liable to you or any supplementary cardmember for any malfunction or failure of the card or refusal by a merchant to accept the card. Clause required under the Consumer Protection Act. (Open credit contract for the use of a credit card)

  • Limitation on Use COLLEGE and SCHOOL DISTRICT shall use each student education record that he or she may receive pursuant to this CCAP Agreement solely for a purpose(s) consistent with his or her authority to access that information pursuant to Federal and State law, as may be as applicable. (34 C.F.R. § 99.31, 34 C.F.R. § 99.34, and Education Code § 49076.)

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Limitation on Liability The Company and the Underwriters agree that it would not be just and equitable if contribution pursuant to this Section 7 were determined by pro rata allocation (even if the Underwriters were treated as one entity for such purpose) or by any other method of allocation that does not take account of the equitable considerations referred to in paragraph (d) above. The amount paid or payable by an Indemnified Person as a result of the losses, claims, damages and liabilities referred to in paragraph (d) above shall be deemed to include, subject to the limitations set forth above, any legal or other expenses incurred by such Indemnified Person in connection with any such action or claim. Notwithstanding the provisions of this Section 7, in no event shall an Underwriter be required to contribute any amount in excess of the amount by which the total underwriting discounts and commissions received by such Underwriter with respect to the offering of the Securities exceeds the amount of any damages that such Underwriter has otherwise been required to pay by reason of such untrue or alleged untrue statement or omission or alleged omission. No person guilty of fraudulent misrepresentation (within the meaning of Section 11(f) of the Securities Act) shall be entitled to contribution from any person who was not guilty of such fraudulent misrepresentation. The Underwriters’ obligations to contribute pursuant to this Section 7 are several in proportion to their respective purchase obligations hereunder and not joint.

  • Limitation by Law; Severability of Provisions All rights, remedies and powers provided in this Security Agreement may be exercised only to the extent that the exercise thereof does not violate any applicable provision of law, and all the provisions of this Security Agreement are intended to be subject to all applicable mandatory provisions of law that may be controlling and to be limited to the extent necessary so that they shall not render this Security Agreement invalid, unenforceable or not entitled to be recorded or registered, in whole or in part. Any provision in this Security Agreement that is held to be inoperative, unenforceable, or invalid in any jurisdiction shall, as to that jurisdiction, be inoperative, unenforceable, or invalid without affecting the remaining provisions in that jurisdiction or the operation, enforceability, or validity of that provision in any other jurisdiction, and to this end the provisions of this Security Agreement are declared to be severable.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!