Responsibilities of the City The City’s Contract Manager will be responsible for exercising general oversight of the Contractor’s activities in completing the Scope of Work. Specifically, the Contract Manager will represent the City’s interests in resolving day-to-day issues that may arise during the term of this Contract, shall participate regularly in conference calls or meetings for status reporting, shall promptly review any written reports submitted by the Contractor, and shall approve all invoices for payment, as appropriate. The City’s Contract Manager shall give the Contractor timely feedback on the acceptability of progress and task reports.
Additional Obligations of the Company The Company shall: (a) At least three (3) Business Days before filing the Mandatory Registration Statement, furnish to counsel selected by the Holders of a majority of the Registrable Securities covered by such registration statement copies of all such documents proposed to be filed (except for Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q and Current Reports on Form 8-K and any similar or successor reports that have been filed via XXXXX which may be incorporated or deemed to be incorporated by reference thereto), and the Company shall in good faith consider any reasonable comments of such counsel received at least one (1) Business Day prior to filing. (b) Promptly notify the Holders when the Mandatory Registration Statement is declared effective by the Commission. The Company shall respond as promptly as reasonably practicable to any comments received from the Commission with respect to the registration statement or any amendments thereto and shall furnish to the Holders, upon request, any comments of the Commission staff regarding the Holders. The Company shall promptly file with the Commission a request for acceleration of effectiveness in accordance with Rule 461 promulgated under the Securities Act after the Company concludes that the staff of the Commission has no further comments on the filing. (c) Furnish to the Holders such number of copies of a prospectus, including a preliminary prospectus, in conformity with the requirements of the Securities Act, and such other documents as they may reasonably request in order to facilitate the disposition of Registrable Securities owned by them. (d) Use commercially reasonable efforts to register and qualify the securities covered by the Mandatory Registration Statement under such other securities or Blue Sky laws of such U.S. jurisdictions as shall be reasonably requested by the Holders unless an exemption from registration and qualification exists; provided that the Company shall not be required in connection therewith or as a condition thereto to qualify to do business, file a general consent to service of process or subject itself to general taxation in any such states or jurisdictions. (e) Promptly notify each Holder of Registrable Securities covered by the Mandatory Registration Statement at any time when a prospectus relating thereto is required to be delivered under the Securities Act of the happening of any event as a result of which the prospectus included in such registration statement, as then in effect, includes an untrue statement of a material fact or omits to state a material fact required to be stated therein or necessary to make the statements therein not misleading in light of the circumstances then existing (provided that in no event shall such notice contain any material, non-public information regarding the Company) and, when such state of facts no longer exists whether due to passage of time or filing of supplemental disclosure by the Company, the Company shall promptly furnish to each such Holder a reasonable number of copies of any supplement or amendment to such prospectus filed by the Company. (f) Use commercially reasonable efforts to prevent the issuance of any stop order or other suspension of effectiveness of the Mandatory Registration Statement, or the suspension of the qualification of any of the Registrable Securities for sale in any jurisdiction in the United States, and in the event of the issuance of any stop order suspending the effectiveness of such registration statement, or any order suspending or preventing the use of any related prospectus or suspending the qualification of any equity securities included in such registration statement for sale in any jurisdiction, the Company shall use commercially reasonable efforts to obtain promptly the withdrawal of such order. (g) Use commercially reasonable efforts to cause all Shares to be listed on each securities exchange on which the same class of securities issued by the Company are then listed (collectively, the “Trading Markets”), including, without limitation, by the filing of any required additional listing applications. (h) Use commercially reasonable efforts to cooperate with the Holders who hold Registrable Securities being offered and, to the extent applicable, facilitate the timely preparation and delivery of certificates (not bearing any restrictive legend) representing the Registrable Securities sold pursuant to the Mandatory Registration Statement, and enable such certificates to be in such denominations or amounts, as the case may be, as the Holders may reasonably request and registered in such names as the Holders may request. (i) Provide and cause to be maintained a registrar and transfer agent for all Registrable Securities covered by any registration statement from and after a date not later than the effective date of the Mandatory Registration Statement. (j) Not, nor shall any subsidiary or affiliate thereof, identify any Holder as an underwriter in any public disclosure or filing with the SEC or the NASDAQ Stock Market or any other securities exchange or market without the consent of such Holder except as required by law.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Conditions to the Obligation of the Company The respective obligations of the Company, NewCo and Merger Sub to complete the transactions contemplated by this Agreement are subject to the satisfaction of, or compliance with, on or before the Closing Date, each of the following conditions (any of which may be waived by the Company, in whole or in part): (a) The representations and warranties of Parent and the Purchaser in Section 7 shall be true and correct (without giving effect to any “materiality” or “material adverse effect” qualifiers contained therein) as of the date of this Agreement and as of the Closing (except to the extent any such representation or warranty speaks as of the date of this Agreement or any other specific date, in which case such representation or warranty shall have been so true and correct as of such date), except where the failure to be true and correct would not, individually or in the aggregate, have a material adverse effect on the ability of Parent and the Purchaser to consummate timely the transactions contemplated by this Agreement; (b) All of the covenants and agreements Parent or the Purchaser are required to perform or comply with under this Agreement on or before the Closing Date shall have been duly performed and complied with in all material respects; (c) Each of the Commercial Agreements (other than the New Company Distribution Agreements and the Acquired KO Brand Distribution Agreements) shall have been duly executed by Parent, the Purchaser or their Subsidiaries, as applicable, and shall be in full force and effect as of the Closing Date; (d) All of the conditions to the Company’s obligations under Sections 8.1 and 8.3 (other than Section 8.3(f)) of the Asset Transfer Agreement shall have been satisfied or waived (other than those conditions that by their nature can only be satisfied at the Closing, but subject to the satisfaction or waiver of such conditions at the Closing), and the consummation of the transactions contemplated by the Asset Transfer Agreement shall occur concurrently with the Closing; provided, however, that the Company shall not have the right to assert that the foregoing condition set forth in this Section 10.3(d) has not been satisfied if the failure to satisfy such condition results primarily from the Company or NewCo’s failure to perform or comply with its obligations under the Asset Transfer Agreement; and (e) The Company shall have received an opinion of Xxxxx Day, on the basis of certain facts, representations and assumptions set forth in such opinion, dated the Closing Date, to the effect that for U.S. federal income tax purposes the exchanges that occur pursuant to the Merger, the acquisition and issuance of the Shares and the KO Asset Transfer, taken together, shall constitute exchanges described in Section 351 of the Code. In rendering such opinion, such counsel shall be entitled to receive and rely upon representations of officers of NewCo, the Company, Parent and the Purchaser as to such matters as such counsel may reasonably request.
Modifications and Waivers; Obligation of the Company Absolute The Indenture permits, with certain exceptions as therein provided, the amendment thereof and the modification of the rights and obligations of the Company and the rights of the Holders of the Securities of each series to be affected under the Indenture at any time by the Company and the Trustee with the consent of the Holders of at least a majority in principal amount of the Securities at the time Outstanding of each series to be affected. The Indenture also contains provisions permitting the Holders of specified percentages in principal amount of the Securities of each series at the time Outstanding, on behalf of the Holders of all Securities of such series, to waive compliance by the Company with certain provisions of the Indenture and certain past defaults under the Indenture and their consequences. Any such consent or waiver by the Holder of this Security shall be conclusive and binding upon such Holder and upon all future Holders of this Security and of any Security issued upon the registration of transfer hereof or in exchange herefor or in lieu hereof, whether or not notation of such consent or waiver is made upon this Security. No reference herein to the Indenture and no provision of this Security or of the Indenture shall alter or impair the obligation of the Company, which is absolute and unconditional, to pay the principal of and interest on this Security at the times, places and rate, and in the coin or currency, herein prescribed.
Conditions Precedent to Obligation of the Company The obligation of the Company to effect the Exchange and otherwise consummate the transactions contemplated by this Agreement is subject to the satisfaction, at or prior to the Closing, of each of the following conditions:
Formation of the Company The Company was formed as a limited liability company under the Act on April 24, 2008. The Member hereby agrees that the person executing and filing the Certificate of Formation of the Company was and is an “authorized person” within the meaning of the Act, and that the Certificate of Formation filed by such authorized person is the Certificate of Formation of the Company.
Conditions Precedent to the Obligation of the Company to Sell the Shares The obligation hereunder of the Company to issue and sell the Shares is subject to the satisfaction or waiver, at or before the Closing, of each of the conditions set forth below. These conditions are for the Company’s sole benefit and may be waived by the Company at any time in its sole discretion.
RESPONSIBILITIES OF THE UNIVERSITY The UNIVERSITY shall designate in writing a faculty member to coordinate with a designee of the FIELDWORK SITE.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services. 12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any. 12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
