Xxxxx of License; Limitations The Engineer is granted a limited revocable non-exclusive license to use the registered TxDOT trademark logo (TxDOT Flying “T”) on any deliverables prepared under this contract that are the property of the State. The Engineer may not make any use of the registered TxDOT trademark logo on any other materials or documents unless it first submits that request in writing to the State and receives approval for the proposed use. The Engineer agrees that it shall not alter, modify, dilute, or otherwise misuse the registered TxDOT trademark logo or bring it into disrepute.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Termination by Licensee Licensee, at its option, may terminate the Agreement by providing Licensor written notice of intent to terminate, which such termination effective will be ninety (90) days following receipt of such notice by Licensor.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Termination by Licensor Without Notice Licensee shall be deemed to be in default under this Agreement, and all rights granted herein shall automatically terminate without notice to Licensee, if Licensee becomes insolvent or makes a general assignment for the benefit of creditors; or if a petition in bankruptcy is filed by Licensee or against Licensee and not opposed by Licensee within sixty (60) days of such filing; or if Licensee is adjudicated as bankrupt or insolvent; or if a bill xx equity or other proceeding for the appointment of a receiver of Licensee or other custodian for Licensee's business or assets if filed and consented to by Licensee; or if a receiver or other permanent or temporary custodian of Licensee's assets or property, or any part thereof, is appointed by any court of competent jurisdiction; or if proceedings for a composition with creditors under any state or federal law should be instituted by or against Licensee; or if a material final judgment remains unsatisfied or of record for thirty (30) days or longer (unless supersedeas bond is filed); or if Licensee is dissolved; or if a suit to foreclose any lien or mortgage against real or personal property used in the operation of Licensee's business, the loss of which would have a material adverse effect on Licensee, is instituted against Licensee and not dismissed within thirty (30) days; or if execution is levied against Licensee's business or property, the loss of which would have a material adverse effect on Licensee; or if real or personal property of Licensee used in its business, the loss of which would have a material adverse effect on Licensee, shall be sold after levy thereupon by any sheriff, marshal, or constable; or if Licensee at any time ceases to operate or otherwise abandons its business or otherwise forfeits the right to do or transact business in any market(s) in the Territory; or if Licensee loses any government license required to engage in the Business or otherwise forfeits the right to do or transact business in one or more market(s), in which event Licensee's rights under this Agreement shall automatically terminate.
Benefits of Agreement; No Third-Party Rights The provisions of this Agreement are intended solely to benefit the Member and, to the fullest extent permitted by applicable law, shall not be construed as conferring any benefit upon any creditor of the Company (and no such creditor shall be a third-party beneficiary of this Agreement), and the Member shall have no duty or obligation to any creditor of the Company to make any contributions or payments to the Company.
Standard of Care; Reliance on Records and Instructions; Indemnification BISYS shall use its best efforts to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Trust for any action taken or omitted by BISYS in the absence of bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties. The Trust agrees to indemnify and hold harmless BISYS, its employees, agents, directors, officers and nominees from and against any and all claims, demands, actions and suits, whether groundless or otherwise, and from and against any and all judgments, liabilities, losses, damages, costs, charges, counsel fees and other expenses of every nature and character arising out of or in any way relating to BISYS' actions taken or nonactions with respect to the performance of services under this Agreement or based, if applicable, upon reasonable reliance on information, records, instructions or requests given or made to BISYS by the Trust, the investment adviser and on any records provided by any fund accountant or custodian thereof; provided that this indemnification shall not apply to actions or omissions of BISYS in cases of its own bad faith, willful misfeasance, negligence or from reckless disregard by it of its obligations and duties; and further provided that prior to confessing any claim against it which may be the subject of this indemnification, BISYS shall give the Trust written notice of and reasonable opportunity to defend against said claim in its own name or in the name of BISYS.
INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Limitations on License (a) This license is not assignable or transferable by operation of law or otherwise, except upon the express written consent of the parties, but no assignment shall relieve the parties of their respective obligations as to performances rendered, acts done and obligations incurred prior to the effective date of the assignment.
(b) This license authorizes performances by means of “Mechanical Music” only; this license does not authorize live performances.
(c) This license is strictly limited to the theater or production venue where each Community Theatre Production is presented, and does not authorize any performances other than those made at the theatre or production venue premises.
(d) This license does not authorize the broadcasting, telecasting or transmission by wire, Internet, webcasting, or on-line service, or otherwise of renditions of musical compositions in the ASCAP repertory to persons outside of the theatre premises where each Community Theatre Production shall be presented.
(e) This license is limited to non-dramatic performances, and does not authorize any dramatic performances. For purposes of this Agreement, a dramatic performance shall include, but not be limited to, the following:
(i) performance of a “dramatico-musical work” in its entirety;
(ii) performance of one or more musical compositions from a “dramatico-musical work” accompanied by dialogue, pantomime, dance, stage action, or visual representation of the work from which the music is taken;
(iii) performance of one or more musical compositions as part of a story or plot, whether accompanied or unaccompanied by dialogue, pantomime, dance, stage action or visual representation;
(iv) performance of a concert version of a “dramatico-musical work”; The term “dramatico-musical work” includes, but is not limited to, a musical comedy, opera, play with music, revue or ballet.
(f) ASCAP reserves the right at any time to withdraw from its repertory and from operation of this license, any musical work as to which any suit has been brought or threatened on a claim that such composition infringes a composition not contained in ASCAP’s repertory, or on a claim that ASCAP does not have the right to license the performing rights in such composition.
(g) This license does not authorize any performance by means of a coin-operated phonorecord player (jukebox) for which a license is otherwise available from the Jukebox License Office.
(h) This license is limited to the United States, its territories and possessions, and Puerto Rico.
