Access to Project Site Redeveloper shall permit the representatives of the City to enter Project Site at any and all reasonable times, as the City may deem necessary for the purposes of this Redevelopment Agreement, including but not limited to work and inspection of all work being performed in connection with the construction of the Redeveloper Improvements. Similarly, the City shall permit Redeveloper such entry upon the public rights of way for such purposes. No compensation shall be payable nor shall any charges be made in any form by any party for the access or inspection provided for in this Section. The City’s right of access granted under this Section shall terminate upon issuance by the City of the Redeveloper’s Certificate of Completion of Redeveloper Improvements. Notwithstanding the above, Redeveloper shall not be relieved of the provisions contained in Chapter 14.29 of the Lincoln Municipal Code regarding the use of streets for private construction purposes.
Ingress and Egress Seller represents that there is ingress and egress to the Real Property and title to 400 the Real Property is insurable in accordance with STANDARD A without exception for lack of legal right of access.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
Access to Properties Subject to the rights of Tenants, Borrower shall permit agents, representatives and employees of Lender to inspect the Properties or any part thereof at reasonable hours upon reasonable advance notice.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Access to Property Borrower shall permit agents, representatives and employees of Lender to inspect the Property or any part thereof at reasonable hours upon reasonable advance notice.
Compliance with Federal and State Work Authorization and Immigration Laws The Contractor and all subcontractors, suppliers and consultants must comply with all federal and state work authorization and immigration laws, and must certify compliance using the form set forth in Section 7 (“Georgia Security and Immigration Compliance Act Affidavits”). The required certificates must be filed with the Owner and copied maintained by the Contractor as of the beginning date of this contract and each subcontract, supplier contract, or consultant contract, and upon final payment to the subcontractor or consultant. State officials, including officials of the Georgia Department of Audits and Accounts, officials of the Owner, retain the right to inspect and audit the Project Site and employment records of the Contractor, subcontractors and consultants without notice during normal working hours until Final Completion, and as otherwise specified by law and by Rules and Regulations of the Georgia Department of Audits and Accounts.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
