Capital Improvements From and after Final Completion, Tenant shall not replace or materially alter the Project, or any part thereof (except as provided to the contrary with respect to Fixtures in Article 13), or make any addition thereto, whether voluntarily or in connection with repairs required by this Lease (collectively, “Capital Improvements”), unless Tenant shall comply with the following requirements and, if applicable, with the additional requirements set forth in Section 11.10: (a) No Capital Improvements shall be undertaken, as applicable, until Tenant shall have procured from all Governmental Authorities and paid for all permits, consents, certificates and approvals for the proposed Capital Improvements which are required to be obtained prior to the commencement of the proposed Capital Improvements (collectively, “Improvement Approvals”). The FCRHA shall not unreasonably refuse to join or otherwise unreasonably refuse to cooperate in the application for any such Improvement Approvals, provided such application is made without cost, expense or liability (contingent or otherwise) to the FCRHA. True copies of all such Improvement Approvals shall be delivered by Tenant to the FCRHA prior to commencement of the proposed Capital Improvements. (b) The Premises after completion of such Capital Improvements, shall have a value at least equal to the value of the Premises immediately before construction of such Capital Improvements. In addition, the Project shall at all times remain in substantial conformity with the original Plans and Specifications therefor (except to the extent specifically consented to by the FCRHA, in its sole but reasonable discretion). (c) All Capital Improvements shall be made with reasonable diligence and continuity (subject to Unavoidable Delays) and in a good and workmanlike manner and in compliance with (i) all Improvement Approvals, (ii) if required pursuant to Section 11.10(a) or (b), in substantial accordance with the plans and specifications for such Capital Improvements as approved by the FCRHA, and (iii) all Applicable Laws. (d) No construction of any Capital Improvement shall be commenced until Tenant shall have delivered to the FCRHA certificates of insurance and copies of the declaration page(s) for the insurance required by Exhibit D. Such insurance policies shall comply with the terms of Section 7.02 above.
Existing Improvements All improvements located on the Site as of the date of execution of the Construction Contract, whether above or below the surface of the ground, including but not limited to existing buildings, utilities, infrastructure improvements and other facilities.
Improvements and Alterations (a) Landlord shall deliver the Premises to Tenant, and Tenant agrees to accept the Premises from Landlord in its existing “AS-IS”, “WHERE-IS” and “WITH ALL FAULTS” condition, and Landlord shall have no obligation to refurbish or otherwise improve the Premises throughout the Lease Term; provided, however, and notwithstanding the foregoing to the contrary Landlord’s sole construction obligation under this Lease is set forth in the Work Letter attached hereto as Exhibit B. In addition, with respect to the area in the Suite 600 Space generally shown in Exhibit I attached hereto and incorporated herein for all purposes, Landlord at its sole cost and expense, agrees (i) to add five 12” Building standard cooling only VAV boxes, (ii) that a new supply air plenum will be added to the box and the supply air tap-outs will be cut in, (iii) that a total of four 12-inch supply air diffusers will be installed in a quadrant pattern, and (iv) that all thermostats will be relocated to their respective zones. (b) Any alterations, additions, or improvements made by or on behalf of Tenant to the Premises (“Alterations”) shall be subject to Landlord’s prior written consent. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Laws and shall construct, at its sole cost and expense, any alteration or modification required by Laws as a result of any Alterations. All Alterations shall be constructed at Tenant’s sole cost and expense and in a good and workmanlike manner by contractors reasonably acceptable to Landlord and only good grades of materials shall be used. All plans and specifications for any Alterations shall be submitted to Landlord for its approval. Landlord may monitor construction of the Alterations. Tenant shall reimburse Landlord for all out-of-pocket sums, if any paid by Landlord for third party examination of Tenant’s plans and specifications for any Alterations. In addition, Tenant shall be obligated to pay Landlord a coordination fee equal to ten percent (10%) of the actual costs of any of such Alterations, which coordination fee shall be paid to Landlord promptly following the completion of the construction of the Alterations. Such coordination fee will be deemed to cover all of Landlord’s costs and expenses for Landlord’s employees or contractors, including but not limited to management personnel, engineers and other consultants involved in review, approval coordination and/or supervision of the Alterations. Landlord’s right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to see that such plans and specifications or construction comply with applicable laws, codes, rules and regulations. Without limiting the other grounds upon which Landlord may refuse to approve any contractor or subcontractor Landlord may take into account the desirability of maintaining harmonious labor relations at the Project. Landlord may also require that all life safety related work and all mechanical electrical plumbing and roof related work be performed by contractors designated by Landlord. Landlord shall have the right, in its sole discretion to instruct Tenant to remove those improvements or Alterations from the Premises which (i) were not approved in advance by Landlord (ii) were not built in conformance with the plans and specifications approved by Landlord or (iii) Landlord specified during its review of plans and specifications for Alterations would need to be removed by Tenant upon the expiration of this Lease. Except as set forth in the preceding sentence, Tenant shall not be obligated to remove such Alterations at the expiration of this Lease. Landlord shall not unreasonably withhold or delay its approval with respect to what improvements or Alterations Landlord may require Tenant to remove at the expiration of the Lease. If upon the termination of this Lease, Landlord require Tenant to remove any or all of such Alterations from the Premises, then Tenant, al Tenant’s sole cost and expense, shall promptly remove such Alterations and improvements and Tenant shall repair and restore the Premises to its original condition as of the Commencement Date, reasonable wear and tear excepted. Any Alterations remaining in the Premises following the expiration of the Lease Term or following the surrender of the Premises from Tenant to Landlord, shall become the property of Landlord unless Landlord notifies Tenant otherwise. Tenant shall provide Landlord with the identities and mailing addresses of
Common Area Maintenance Landlord will maintain or cause to be maintained the Common Areas and Tenant will reimburse Landlord for Tenant’s prorata share of the cost of such maintenance as hereinafter provided. (a) Common area maintenance costs and expenses shall be determined in accordance with generally accepted accounting principles consistently applied and allocated to any particular calendar year on the accrual method of accounting. Such costs and expenses shall include, but shall not be limited to upkeep, exterior painting, repairs, replacements and improvements in the Common Areas, snow removal, sweeping and cleanup, depreciation allowance on any machinery and equipment owned by Landlord and used in connection therewith, utility services including fire line water service charges, premiums for public liability, property damage and fire insurance including the Common Areas, any real estate tax and/or tax consultant expense incurred for the purpose of maintaining equitable tax assessments on the Development, all property taxes or assessments levied or assessed against all Common Areas, which, if not separately assessed, shall be determined, for land, by the ratio of land area designated for Common Area use to the total land area in the Development and, for improvements, on a fair and equitable allocation among the various improvements in the Development, giving weight to the factors which determine the amount of the real property tax or assessment in question. In addition, such costs shall include administrative costs equal to ten percent (10%) of the total cost paid or incurred by Landlord under this paragraph. (b) Tenant shall pay as additional rent to Landlord, Tenant’s prorata share of such Common Area expenses in the following manner: (1) From and after the date the minimum rental provided for herein has commenced, but subject to adjustment as hereinafter in this subparagraph (1) provided, Tenant shall pay Landlord in advance on the first day of each calendar month during the term of this Lease an estimated and adjustable amount covering Tenant’s proportionate share of common area services and expenses, which amount may be adjusted by Landlord by notice to Tenant at the end of any calendar month on the basis of Landlord’s experience and reasonably anticipated costs. (See Lease Rider “A” Building Expenses attached hereto and incorporated herein.) (2) Within thirty (30) days following the end of each calendar year, Landlord shall furnish Tenant a statement covering the calendar year just expired, showing the total operating costs, the amount of Tenant’s prorata share of such Common Area expenses for such calendar year and the payments made by Tenant with respect to such calendar year as set forth in subparagraph (b) I. If Tenant’s prorata share of such Common Area expenses exceeds Tenant’s payments so made, Tenant shall pay Landlord the deficiency within ten (10) days after receipt of such statement. If said payments exceed Tenant’s prorata share of such Common Area expenses, Tenant shall be entitled to offset the excess against payments next thereafter to become due Landlord as set forth in said subparagraph (b) I. Tenant’s pro-rata share of the total Common Area expenses for the previous calendar year shall be that portion of all such expenses which is equal to the proportion which the number of square feet of gross leasable area in the Demised Premises bears to the total number of square feet of gross leasable area of buildings in the entire Development which are from time to time completed and occupied as of the commencement of each calendar year.
ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Initial Improvements (a) On the Commencement Date, Tenant shall accept the Premises in its “as is” condition. All improvements, alterations and betterments (an “Alteration”) shall be performed by Tenant at Tenant’s expense in accordance with the terms of this Article 5. (b) Tenant may improve the Premises for Tenant’s initial occupancy in accordance with detailed specifications and working drawings to be prepared by Tenant’s engineers and architects. The detailed specifications and working drawings are hereinafter referred to as “Tenant’s Plans”, and the work shown by the Tenant’s Plans is hereinafter referred to as “Tenant’s Initial Improvements”. Tenant’s Initial Improvements shall include, and Landlord shall have no liability to tenant for not performing, the work specified on Exhibit H. (c) Tenant shall proceed forthwith to cause Tenant’s Plans to be prepared by an architect licensed as such in the State of New York. Tenant’s Plans, including structural and mechanical drawings and specifications, shall be prepared at Tenant’s sole cost and expense. Tenant shall submit five (5) sets of Tenant’s Plans and two (2) CAD discs which shall contain such Tenant’s Plans in CAD format to Landlord for Landlord’s approval. Landlord agrees to review Tenant’s Plans and to approve the same or make written exceptions thereto within fifteen (15) Business Days from the date of the submission of the plans. Landlord agrees not to unreasonably withhold or delay its approval of Tenant’s Plans, and failure by Landlord to provide the written exceptions within the fifteen (15) Business Day period aforesaid shall be deemed approval of Tenant’s Plans; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS” in bold lettering at the top of such notice. If Landlord disapproves Tenant’s Plans, Tenant shall revise them and re-submit them to Landlord for approval. Any disapproval given by Landlord shall be accompanied by a statement in reasonable detail of the reasons for such disapproval, itemizing those portions of the plans so disapproved. Landlord shall advise Tenant within fifteen (15) Business Days following receipt of Tenant’s revised plans of Landlord’s approval or disapproval of the revised plans or portions thereof, and shall set forth its reasons for any such further disapproval in writing and in reasonable detail. If Landlord fails to approve or disapprove such revised plans within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such revised plans or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Any dispute regarding the reasonableness of Landlord’s withholding of its consent to Tenant’s Plans shall be submitted to expedited arbitration pursuant to Section 9.19 hereof. Upon approval by Landlord of Tenant’s Plans, Tenant shall submit the same to the New York City Department of Buildings for approval and for issuance of a building permit to perform the Improvements. Landlord agrees, at Tenant’s cost and expense, to reasonably cooperate with Tenant and Tenant’s independent licensed architect and engineer in providing information needed for the preparation of Tenant’s Plans, the application for a building permit and all other permits required for the Improvements, and to promptly execute all documents reasonably necessary to be signed by Landlord. (d) Tenant agrees to hire a reputable general contractor, construction manager or subcontractors and materialmen (hereinafter “Contractor(s)”) to be approved by Landlord such approval not to be unreasonably withheld or delayed (other than with respect to Contractors performing connections to any Building systems which Contractors shall be those designated by Landlord provided such Contractors shall perform such work at market prices). For purposes of Tenant’s Initial Improvements, Xxxxx, Xxxx & Xxxxxx and Xxxxxx Xxxxxxxx Consulting Engineers are deemed approved by Landlord. Tenant shall cause its Contractor(s) to perform Tenant’s Initial Improvements in a good and workmanlike manner in accordance with (x) the approved Tenant’s Plans and any material amendments or additions thereto approved by Tenant and Landlord and all municipal authorities having jurisdiction; provided, however, that, with respect to any subsequent amendments, additions, change orders or modifications after Landlord’s approval of Tenant’s Plans, Landlord shall approve or disapprove of such changes within fifteen (15) Business Days of the receipt of such changes from Tenant and (y) all provisions of Laws and any and all permits and other requirements specified by any ordinance, law or public regulation. If Landlord fails to approve or disapprove such subsequent amendments, additions, change orders or modifications within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such subsequent amendments, additions, change orders or modifications or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Tenant shall cause the Contractor(s) to obtain and maintain throughout the work, Workers’ Compensation Insurance and New York State Disability Insurance in the amounts required under any applicable Laws and comprehensive general liability insurance, including contractual liability coverage, in an amount of not less than $2 million combined single limit for bodily injury or death for any one occurrence, and for property damage, plus a $10 million umbrella policy; provided, however, that any subcontractor or materialman shall only be required to carry such liability insurance as is being carried by prudent subcontractors or materialmen within such trade at the time such subcontractor or materialman is being employed by Tenant or its Contractors. The liability coverage shall name Landlord and Overlandlord as additional insured parties, and Tenant shall deliver to Landlord proper certificates of insurance confirming the coverages described above prior to commencement of Tenant’s Initial Improvements. If Tenant acts as its own General Contractor or Construction Manager, Tenant shall obtain and maintain such insurance. All Contractor(s) shall be members of a union affiliated with the building trades in the City of New York that has jurisdiction over the Building and Tenant’s Initial Improvements. Tenant shall pay Landlord, within thirty (30) days after being billed therefor, the actual out of pocket fees and disbursements paid by Landlord to architects, engineers and other technical advisors, other than the regular staff of Landlord for reviewing Tenant’s Plans, provided such fees are commercially reasonable. (e) Landlord shall pay to Tenant pursuant to Section 5.01(f) hereof Construction Costs and Softs Costs (as hereinafter defined) in an amount (the “Construction Allowance”) which shall not exceed $1,638,850.00, provided, however, that payments in respect of Soft Costs shall not in the aggregate exceed fifteen percent (15%) of the Construction Allowance. Tenant shall pay from its own funds, and Landlord shall have no obligation with respect to, (y) any and all costs which are not Construction Costs or Softs Costs and/or (z) any and all Construction Costs in excess of the Construction Allowance or Soft Costs in excess of the limitation described in the foregoing sentence. As used in this Lease, the term “Construction Costs” means amounts actually incurred and paid by Tenant and Tenant’s contractors, subcontractors and vendors in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of (i) construction supplies and materials which are physically installed in and made a part of the Premises, including the documented, bona fide costs of carpeting, wall coverings, partitions, any electric meter or submeter, and permit fees, and (ii) labor actually performed within the Premises. The term “Soft Costs” means amounts actually incurred and paid by Tenant in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of accounting, legal, architectural, engineering and other professional or consulting services.
Construction of Tenant Improvements Tenant shall install the Tenant Improvements (as described in Paragraph 2(a) below) in accordance with the terms and conditions of this Work Letter. The quantities, character and manner of installation of all of the work related to the Tenant Improvements shall be subject to the limitations imposed by any applicable governmental regulations, laws, ordinances, codes and rules. Notwithstanding the foregoing, Landlord may at Landlord’s sole election itself (with Landlord’s contractor) construct the portion of the Tenant Improvements that consist of the restrooms and related improvements that will service Building 2 (the “Restroom Improvements”), at Tenant’s cost up to a maximum amount of $322,764 (subject to Section 9(b) below), provided that (a) Landlord notifies Tenant in writing of such election prior to Tenant’s commencement of construction of the Tenant Improvements, and (b) Landlord shall use commercially reasonable efforts to not unreasonably interfere with or delay Tenant’s installation of the Tenant Improvements. If a certificate of occupancy or equivalent permit sign-off for the Premises is delayed beyond the Building 2 Scheduled Commencement Date solely as a result of Landlord’s failure to substantially complete the Restroom Improvements prior to such date, which failure does not result from Tenant Delays (as defined below) or Force Majeure, then the Building 2 Commencement Date shall be extended day for day by the number of days after the Building 2 Scheduled Commencement Date until the issuance of a certificate of occupancy or equivalent permit sign-off (but in no event shall the Building 2 Commencement Date be delayed beyond the date Tenant commences business in the Premises), provided, however, that Tenant delivers written notice to Landlord at such time as Tenant becomes aware that Landlord is in danger of causing such delay. “Tenant Delays” shall mean (i) Tenant’s delay in submittal of Tenant’s Plans and/or responses to Landlord’s comments to Tenant’s Plans beyond the time periods provided in this Work Letter, (ii) Tenant’s delay in any submittals for permits or other governmental approvals with respect to the Tenant Improvements (including without limitation the Restroom Improvements), (iii) changes in Tenant’s Plans as they relate to the Restroom Improvements after they have been submitted to governmental authorities for permits, (iv) delay in obtaining materials for reasons outside Landlord’s reasonable control, and (v) Tenant’s failure to provide reasonable access to the Premises to Landlord’s contractors to install the Restroom Improvements, or unreasonable interference with such installation by Tenant or its contractors or agents.
Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.