Construction Phase During Construction, DESIGN/BUILDER shall provide Engineering and Design Professional Services as necessary to complete the Project.
Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)
General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Completion of Construction (a) For the purposes of this Agreement, the terms "
Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).
Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.
Specific Shall Not Limit General; Construction No specific provision contained in this Note shall limit or modify any more general provision contained herein. This Note shall be deemed to be jointly drafted by the Company and the Holder and shall not be construed against any person as the drafter hereof.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.
