Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.
Construction Documents Phase Bidding or Negotiation Phase:
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner.
1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved.
1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract.
1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project.
1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development.
1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments.
1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments.
1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.
Description of the Transaction Documents The Transaction Documents will conform in all material respects to the respective statements relating thereto contained in the Offering Memorandum.
Acquisition Documents As of the Closing Date:
(a) Borrower has furnished Bank with true, correct and complete execution copies of all Acquisition Documents. Borrower has taken all necessary corporate action to authorize the execution, delivery and performance of each Acquisition Document to which it is a party.
(b) Borrower has complied with all applicable federal, state, provincial and local laws, ordinances, codes, rules, regulations and guidelines (including consent decrees and administrative orders) relating to the consummation of the Acquisition and all applicable waiting periods with respect to the transactions contemplated by the Acquisition Documents have expired without any action being taken by any competent governmental authority which restrains, prevents or imposes material adverse conditions upon the consummation of such transactions.
(c) All necessary authorization, consent, approval, license, qualification or formal exemption from, and all necessary filing, declaration or registration with, any court, governmental agency or regulatory authority or any securities exchange or any other Person (whether or not governmental, and including without limit any shareholder, partner or member of an applicable party) required to be made prior to the closing of the Acquisition in connection with the execution, delivery and performance by Borrower, and to Borrower’s best knowledge, each other party to the Acquisition Documents to which Borrower or such other Person is a party, have been obtained and will be in full force and effect, and, to the knowledge of Borrower, are not the subject of any attack or threatened attack (in each case in any material respect) by appeal or direct proceeding or otherwise.
(d) The execution, delivery and performance of the Acquisition Documents, and the consummation of the transactions contemplated thereby, are not in contravention of the terms of any indenture, material contract, instrument, any judgment, order or decree, to which Borrower is a party or by which it or its properties are bound, except, in each case, where such contravention could not reasonably be expected to have a Material Adverse Effect.
(e) Borrower has not granted a collateral assignment of, or a security interest over the Acquisition Documents (other than in favor of Bank) and Borrower has not sold, transferred or assigned any Acquisition Document to any Person (other than to or in favor of Bank).
(f) No Acquisition Document to which Borrower is a party has been modified, amended, altered or changed in any manner except in compliance with Section 7.12 of this Agreement, and to Borrower’s best knowledge, there are no unwaived defaults existing under the Acquisition Documents by Borrower that is a party thereto, or, to the best of the knowledge of Borrower, by any other party thereto.
Formation Documents With respect to the Issuing Entity, the Certificate of Trust and the Trust Agreement, (ii) with respect to the Grantor Trust, the Grantor Trust Certificate of Trust and the Grantor Trust Agreement, and (iii) with respect to the Depositor, the certificate of formation of the Depositor filed in Delaware, dated as of January 4, 2019 and the amended and restated limited liability company agreement of the Depositor, dated as of March 27, 2019, made by the Sponsor, as member.
Authorization Documents For each Loan Party, such Person’s (a) charter (or similar formation document), certified by the appropriate governmental authority; (b) good standing certificates in its state of incorporation (or formation) and in each other state requested by the Administrative Agent; (c) bylaws (or similar governing document); (d) resolutions of its board of directors (or similar governing body) approving and authorizing such Person’s execution, delivery and performance of the Loan Documents to which it is party and the transactions contemplated thereby; and (e) signature and incumbency certificates of its officers executing any of the Loan Documents (it being understood that the Administrative Agent and each Lender may conclusively rely on each such certificate until formally advised by a like certificate of any changes therein), all certified by its secretary or an assistant secretary (or similar officer) as being in full force and effect without modification.
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:
1. Coordination and providing supervision to all Subcontractor and workers;
2. Posting of the prevailing wage scale;
3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel;
4. Conducting weekly on-site safety meetings;
5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day.
a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day.
b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered.
c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation.
6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.
