Product Liability The Company has no Liability (and there is no basis for any present or future action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand against any of them giving rise to any Liability) arising out of any injury to individuals or property as a result of the ownership, possession, or use of any product manufactured, sold, leased, or delivered by the Company.
DEFECT LIABILITY It is agreed that in case any structural defect or any other defect in workmanship, quality or provision of services or any other obligations of the Promoter as per the agreement for sale relating to such development is brought to the notice of the Promoter within a period of 5 (five) years by the Allottee from the date of handing over possession, it shall be the duty of the Promoter to rectify such defects without further charge, within 30 (thirty) days, and in the event of Promoter's failure to rectify such defects within such time, the aggrieved Allottees shall be entitled to receive appropriate compensation in the manner as provided under the Act.
Defects Liability 9.1 In this Contract, and subject to Clause 9.2, a defect shall mean any non-conformity of the Supplies with the express terms of this Contract resulting from circumstances existing in the Supplies at the time of the transfer of risk to the Customer (“Defects”).
9.2 In particular, the following shall not be Defects:
a) normal wear and tear, non-conformity resulting from excessive strain,
b) non-conformity resulting from faulty or negligent handling; non-compliance with instructions or recommendations in operation or maintenance manuals and other documents;
c) installation, erection, modification, commissioning, or pre-commissioning, in each case not carried out by Xxxxxxx,
d) non-reproducible software errors,
e) defects which do not significantly impair the use of the respective Supplies.
9.3 The Customer shall immediately inspect the Supplies upon delivery and shall notify Flender in writing of any Defects without undue delay. The Customer’s claims in respect of defects shall be excluded for any apparent defects if the Customer has failed to do so. Upon such written notification, Flender shall, at its option, remedy a Defect by repair, replacement, or re-performance. Flender shall be given a reasonable period of time and opportunity to remedy the Defect. For this purpose, the Customer shall xxxxx Xxxxxxx working access to the non- conforming Supplies, shall undertake any necessary dis-assembly and re-assembly, and shall provide access to operation and maintenance data, all at no charge to Flender. Upon Flender’s request, the Customer shall ensure that the title to the replaced parts/items shall pass to Flender.
9.4 Unless otherwise agreed, the defects liability period for any part of the Supplies is 12 months. It starts at the date of transfer of risk. For replaced or repaired parts of the Supplies, the defects liability period is 6 months from the date of replacement or repair, if the original defects liability period for the Supplies expires earlier. In any event, the defects liability period shall end no later than 24 months from the beginning of the original defects liability period.
9.5 If software is defective, Flender shall only be obliged to provide the Customer with an updated version of the software in which the Defect has been remedied when such updated version is reasonably available from Flender or, if Flender is only licensee, from Flender’s licensor. If the software has been modified or individually developed by Flender, Flender shall in addition provide the Customer with a workaround or other interim corrective solution until the provision of an updated version of the software, if such workaround or interim solution is feasible at reasonable expense and if otherwise the Customer’s business operations would be substantially impeded.
9.6 If Flender carries out remedial work and it is ultimately not established that there was a Defect, the Customer shall pay Flender for such remedial work including error diagnosis.
9.7 Any other liability of Flender and rights and remedies of the Customer in case of defects of the Supplies, other than those expressly stipulated in this Clause 9 or , in case Flender failed at least three times in remedying the defect, in Clause 15.2b) shall be excluded. All warranties, representations, conditions, and all other terms of any kind whatsoever implied by statute or law are, to the fullest extent permitted by applicable law, excluded from this Contract.
Product Liability Claims As soon as it becomes aware, each party will give the other prompt written notice of any defect or alleged defect in a Product, any injury alleged to have occurred as a result of the use or application of a Product, and any circumstances that may give rise to litigation or recall of a Product or regulatory action that may affect the sale or manufacture of a Product, specifying, to the extent the party has such information, the time, place and circumstances thereof and the names and addresses of the persons involved. Each party will also furnish promptly to the other copies of all papers received in respect of any claim, action or suit arising out of such alleged defect, injury or regulatory action.
Limitation of District Liability Other than as provided in this Agreement, District’s financial obligations under this Agreement shall be limited to the payment of the compensation provided in this Agreement. Notwithstanding any other provision of this Agreement, in no event, shall District be liable, regardless of whether any claim is based on contract or tort, for any special, consequential, indirect or incidental damages, including, but not limited to, lost profits or revenue, arising out of or in connection with this Agreement for the services performed in connection with this Agreement.
Product Warranty and Product Liability Set forth in Schedule 3.14 of the Disclosure Schedule is a true, correct and complete copy of the Company's standard warranty or warranties for sales of its products.
Products Liability (a) Except as set forth on Schedule 3.25, (i) there is no Action before any Governmental Entity pending, or to the Knowledge of the Seller, threatened against the Company involving any products manufactured, produced, distributed or sold by or on behalf of the Company and/or in connection with the Business (including any parts or components) (collectively, “Products”), or class of claims or lawsuits involving the same or similar Product which is pending or, to the Seller’s Knowledge, threatened, resulting from an alleged defect in design, manufacture, materials or workmanship of any Product, or any alleged failure to warn, or from any breach of implied warranties or representations (collectively, “Product Liability Lawsuits”); (ii) there has not been, within the past 12 months, any Occurrence (as hereinafter defined); and (iii) there has not been, within the past 12 months, any Product rework or retrofit (collectively, “Retrofits”) conducted by or on behalf of the Company.
(b) For purposes of this Section 3.25, the term “Occurrence” shall mean any accident, happening or event which takes place at any time which is caused or allegedly caused by any alleged hazard or alleged defect in manufacture, design, materials or workmanship including, without limitation, any alleged failure to warn or any breach of express or implied warranties or representations with respect to, or any such accident, happening or event otherwise involving any Product that can reasonably be expected to result in a claim or loss.
(c) Except as set forth on Schedule 3.25, to the Seller’s Knowledge, each Product manufactured, sold, leased, or delivered by the Company and the Business has been in conformity with all applicable material contractual commitments and all express and implied warranties, and the Company and the Business have no Liability (and there is no basis for any present or future proceeding against any of them giving rise to any Liability) for replacement or repair thereof or other damages in connection therewith. No Product manufactured, sold, leased, or delivered by the Company and the Business is subject to any guaranty, warranty, or other indemnity beyond the applicable standard terms and conditions of sale or lease. Schedule 3.25 includes copies of the standard terms and conditions of sale or lease for the Company and the Business (containing applicable guaranty, warranty, and indemnity provisions). Except as set forth on Schedule 3.25, the Seller and the Business have no obligation to any person to maintain, modify, improve or upgrade any of the Products.
(d) Except as set forth on Schedule 3.25, to the Seller’s Knowledge, the Company and the Business have no material Liability (and there is no basis for any present or future proceeding against any the Company and the Business giving rise to any material Liability) arising out of any injury to individuals or property as a result of the ownership, possession, or use of any Product manufactured, sold, leased, or delivered by the Company and the Business.
Limitations of contractual liability No Party shall be responsible to any other Party for any indirect or consequential loss or similar damage such as, but not limited to, loss of profit, loss of revenue or loss of contracts, provided such damage was not caused by a willful act or by a breach of confidentiality. For any remaining contractual liability, a Party’s aggregate liability towards the other Parties collectively shall be limited to the Party’s share of the total costs of the Project as identified in Project Contract, provided such damage was not caused by a willful act or gross negligence. The terms of the Partnership Agreement shall not be construed to amend or limit any Party’s statutory liability.
LIMITATION OF CONTRACTOR’S LIABILITY Except as specified in any separate writing between the Contractor and an END USER, Contractor’s total liability under this Agreement, whether for breach of contract, warranty, negligence, strict liability, in tort or otherwise, but excluding its obligation to indemnify H-GAC, is limited to the price of the particular products/services sold hereunder, and Contractor agrees either to refund the purchase price or to repair or replace product(s) that are not as warranted. In no event will Contractor be liable for any loss of use, loss of time, inconvenience, commercial loss, loss of profits or savings or other incidental, special or consequential damages to the full extent such use may be disclaimed by law. Contractor understands and agrees that it shall be liable to repay and shall repay upon demand to END USER any amounts determined by H-GAC, its independent auditors, or any agency of State or Federal government to have been paid in violation of the terms of this Agreement.
Liability of NCPS a. NCPS undertakes to perform only such duties as are expressly set forth herein and no duties shall be implied. NCPS shall have no liability under and no duty to inquire as to the provisions of any agreement other than this Escrow Agreement, including without limitation the Offering Document. NCPS shall not be liable for any action taken or omitted by it in good faith except to the extent that a court of competent jurisdiction determines that NCPS’s gross negligence or willful misconduct was the primary cause of any loss to the Issuer, Broker or any Subscriber. NCPS’s sole responsibility shall be for the safekeeping and disbursement of the Escrow Funds in accordance with the terms of this Escrow Agreement. NCPS shall have no implied duties or obligations and shall not be charged with knowledge or notice of any fact or circumstance not specifically set forth herein. NCPS may rely upon any notice, instruction, request or other instrument, not only as to its due execution, validity and effectiveness, but also as to the truth and accuracy of any information contained therein, which NCPS shall believe to be genuine and to have been signed or presented by the person or parties purporting to sign the same. In no event shall NCPS be liable for incidental, indirect, special, consequential or punitive damages (including, but not limited to lost profits), even if NCPS has been advised of the likelihood of such loss or damage and regardless of the form of action. NCPS shall not be obligated to take any legal action or commence any proceeding in connection with the Escrow Funds, any account in which Escrow Funds are deposited, this Escrow Agreement or the Offering Document, or to appear in, prosecute or defend any such legal action or proceeding. Without limiting the generality of the foregoing, NCPS shall not be responsible for or required to enforce any of the terms or conditions of any subscription agreement with any Subscriber or any other agreement between Issuer, Broker and/or any Subscriber. NCPS shall not be responsible or liable in any manner for the performance by Issuer or any Subscriber of their respective obligations under any subscription agreement nor shall NCPS be responsible or liable in any manner for the failure of Issuer, Broker or any third party (including any Subscriber) to honor any of the provisions of this Escrow Agreement. NCPS may consult legal counsel selected by it in the event of any dispute or question as to the construction of any of the provisions hereof or of any other agreement or of its duties hereunder, or relating to any dispute involving any party hereto, and shall incur no liability and shall be fully indemnified from any reasonable liability whatsoever in acting in accordance with the reasonable opinion or instruction of such counsel. Issuer shall promptly pay, upon demand, the reasonable fees and expenses of any such counsel.
b. NCPS is authorized, in its sole discretion, to comply with orders issued or process entered by any court with respect to the Escrow Funds, without determination by NCPS of such court's jurisdiction in the matter. If any portion of the Escrow Funds is at any time attached, garnished or levied upon under any court order, or in case the payment, assignment, transfer, conveyance or delivery of any such property shall be stayed or enjoined by any court order, or in case any order, judgment or decree shall be made or entered by any court affecting such property or any part thereof, then and in any such event, NCPS is authorized, in its reasonable discretion, to rely upon and comply with any such order, writ, judgment or decree which it is advised by legal counsel selected by it is binding upon it without the need for appeal or other action; and if NCPS complies with any such order, writ, judgment or decree, it shall not be liable to any of the parties hereto or to any other person or entity by reason of such compliance even though such order, writ, judgment or decree may be subsequently reversed, modified, annulled, set aside or vacated. Notwithstanding the foregoing, NCPS shall provide the Issuer and Broker with immediate notice of any such court order or similar demand and the opportunity to interpose an objection or obtain a protective order.
