Contract Quantity The Contract Quantity during each Contract Year is the amount set forth in the applicable Contract Year in Section D of the Cover Sheet (“Delivery Term Contract Quantity Schedule”), which amount is inclusive of outages.
MINIMUM ORDER QUANTITY The State makes no commitment to purchase any minimum or maximum quantity, or dollar volume of products from the selected suppliers. Utilization of this agreement will be on an as needed basis by State Agencies and/or Cooperative Participants, Cities, Counties, Schools K-12, Colleges and Universities. The State will award to multiple suppliers; however, the State reserves the right to purchase like and similar products from other suppliers as necessary to meet operational requirements.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
VARIATION IN QUANTITY The state assumes no liability for commodities produced, processed or shipped in excess of the amount specified herein.
Contract Year A twelve (12) month period during the term of the Agreement commencing on the Effective Date and each anniversary thereof.
ESTIMATED QUANTITIES 1.1 The quantities set forth in the line items and specification document are approximate and represent the estimated requirements for the contract period.
1.2 Items listed may or may not be an inclusive requirements for this category.
1.3 Category items not listed, but distributed by bidder are to be referred to as kindred items. Kindred items shall receive the same percentage of discount or pricing structure as items listed in the specification document.
1.4 The unit prices and the extended total prices shall be used as a basis for the evaluation of bids. The actual quantity of materials necessary may be more or less than the estimates listed in the specification document, but the City/County shall be neither obligated nor limited to any specified amount. If possible, the Owners will restrict increases/decreases to 20% of the estimated quantities listed in the specification document.
Delivery Point The delivery point is the point of delivery of the Power Product to the CAISO Controlled Grid (the “Delivery Point”). Seller shall provide and convey to Buyer the Power Product from the Generating Facility at the Delivery Point. Title to and risk of loss related to the Power Product transfer from Seller to Buyer at the Delivery Point.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
ESTIMATED / SPECIFIC QUANTITY CONTRACTS Estimated quantity contracts, also referred to as indefinite delivery / indefinite quantity contracts, are expressly agreed and understood to be made for only the quantities, if any, actually ordered during the Contract term. No guarantee of any quantity is implied or given. With respect to any specific quantity stated in the contract, the Commissioner reserves the right after award to order up to 20% more or less (rounded to the next highest whole number) than the specific quantities called for in the Contract. Notwithstanding the foregoing, the Commissioner may purchase greater or lesser percentages of Contract quantities should the Commissioner and Contractor so agree. Such agreement may include an equitable price adjustment.
SALES PRICE A. Cash portion of Sales Price payable by Buyer at closing $
B. Sum of all financing described in the attached: Third Party Financing Addendum, Loan Assumption Addendum, Seller Financing Addendum $ C. Sales Price (Sum of A and B) $
