Maximum Product Inventory Sample Clauses

Maximum Product Inventory. With the exception of each of the first two full calendar months following the Effective Date, at the end of any given full calendar month during the term of this Agreement, Distributor shall not have remaining inventory of any Product in excess of the average biweekly sales of such Product (any such average biweekly sales of such Product, the “Maximum Product Inventory”), determined as follows: (I) calculate the number of stock-keeping units of such Product dispensed to Participants by Distributor during such full calendar month and the preceding two (2) full calendar months; (II) divide by six (6) the number obtained from clause (I) of this sentence; and (III) if the number obtained from clause (II) of this sentence is not a whole number, round up to the next whole number. If Distributor believes that demand for a Product warrants such action, Distributor may submit a written request to Pharmacyclics for a specific increase in the Maximum Product Inventory for a specific Product for a specific full calendar month. Pharmacyclics may, in Pharmacyclics’ sole discretion, provide Distributor with Pharmacyclics’ written authorization for such increase in the Maximum Product Inventory for such Product for such full calendar month. Unless otherwise expressly stated in Pharmacyclics’ written authorization, the increase shall not apply to the Maximum Product Inventory for such Product in any subsequent month.
Sample 1
AutoNDA by SimpleDocs

Related to Maximum Product Inventory

  • Inventory To the extent Inventory held for sale or lease has been produced by any Borrower, it has been and will be produced by such Borrower in accordance with the Federal Fair Labor Standards Act of 1938, as amended, and all rules, regulations and orders thereunder.

  • Physical Inventory The Contractor shall periodically perform, record, and disclose physical inventory results. A final physical inventory shall be performed upon contract completion or termination. The Property Administrator may waive this final inventory requirement, depending on the circumstances (e.g., overall reliability of the Contractor’s system or the property is to be transferred to a follow-on contract).

  • SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.

  • Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.

  • Defective Products A defective product may be returned to PRECISIONARY INSTRUMENTS within thirty (30) days of the delivery date for a refund of the original purchase price with the following amendments/fees. To return a defective product, please contact our Customer Service Department and follow the Return of Products Instructions below.

  • Defective Product If Client rejects Products under Section 6.1 and the deviation is determined to have arisen from Patheon’s failure to provide the Manufacturing Services in accordance with the Specifications, cGMPs, or Applicable Laws, Patheon will credit Client’s account for Patheon’s invoice price for the defective Products. If Client previously paid for the defective Products, Patheon will promptly, at Client’s election, either: (i) refund the invoice price for the defective Products; (ii) offset the amount paid against other amounts due to Patheon hereunder; or (iii) replace the Products with conforming Products without Client being liable for payment therefor under Section 3.1, contingent upon the receipt from Client of all Active Materials and Client-Supplied Components required for the manufacture of the replacement Products. For greater certainty, Patheon’s responsibility for any loss of Active Materials in defective Product will be captured and calculated in the Active Materials Yield under Section 2.2.

  • Eligible Inventory For purposes of this Agreement, Eligible Inventory shall exclude any Inventory to which any of the exclusionary criteria set forth below applies. The Administrative Agent shall have the right to establish, modify or eliminate Reserves against Eligible Inventory from time to time in its reasonable credit judgment. In addition, the Administrative Agent reserves the right, at any time and from time to time after the Original Closing Date, to adjust any of the criteria set forth below, to establish new criteria and to adjust the applicable advance rate with respect to Eligible Inventory, in its reasonable credit judgment, subject to the approval of the Supermajority Lenders in the case of adjustments, new criteria, changes in the applicable advance rate or the elimination of Reserves which have the effect of making more credit available. Eligible Inventory shall not include any Inventory of Borrower or any Borrowing Base Guarantor that: (i) the Collateral Agent, on behalf of Secured Parties, does not have a first priority and exclusive perfected Lien on such Inventory; (ii) is not located on premises in United States or Canada; (iii) (A) is located on premises leased by Borrower or a Borrowing Base Guarantor, unless (x) at such location the aggregate value of Inventory exceeds $250,000, and (y) either (1) a reasonably satisfactory Landlord Lien Waiver and Access Agreement has been delivered to the Collateral Agent, or (2) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto or (B) is stored with a bailee or warehouseman where the aggregate value of Inventory exceeds $250,000 unless either (x) a reasonably satisfactory, acknowledged bailee waiver letter has been received by the Collateral Agent or (y) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto, or (C) is located at an owned location subject to a mortgage in favor of a lender other than the Collateral Agent where the aggregate value of Inventory exceeds $250,000 unless either (x) a reasonably satisfactory mortgagee waiver has been delivered to the Collateral Agent or (y) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto; (iv) is placed on consignment (other than Eligible Consigned Inventory); (v) is covered by a negotiable document of title, unless such document has been delivered to the Collateral Agent with all necessary endorsements, free and clear of all Liens except those in favor of the Collateral Agent and the Lenders and landlords, carriers, bailees and warehousemen if clause (iii) above has been complied with; (vi) is to be returned to suppliers; (vii) is obsolete, unsalable, shopworn, seconds, damaged or unfit for sale; (viii) is slow moving (in excess of 1-year supply); (ix) consists of display items, samples or packing or shipping materials, manufacturing supplies or replacement parts (it being understood that Eligible Inventory shall not exclude work-in-process Inventory if it is not excluded in accordance with other criteria set forth herein, unless otherwise determined by the Administrative Agent in its reasonable credit judgment); (x) is not of a type held for sale in the ordinary course of Borrower’s or any Borrowing Base Guarantor’s, as applicable, business; (xi) breaches any of the representations or warranties pertaining to Inventory set forth in the Loan Documents; (xii) consists of Hazardous Material or goods that can be transported or sold only with licenses that are not readily available; (xiii) is not covered by casualty insurance maintained as required by Section 5.04; (xiv) consists of custom made Inventory which is not saleable to any other customer or in ordinary course; (xv) is in transit; or (xvi) is subject to any licensing arrangement the effect of which would be to limit the ability of Collateral Agent, or any Person selling the Inventory on behalf of Collateral Agent, to sell such Inventory in enforcement of the Collateral Agent’s Liens, without further consent or payment to the licensor or other.

  • Physical Inventories (a) Cause not less than two physical inventories to be undertaken, at the expense of the Loan Parties, in each Fiscal Year and periodic cycle counts, in each case consistent with past practices, conducted by such inventory takers as are reasonably satisfactory to the Collateral Agent and following such methodology as is consistent with the methodology used in the immediately preceding inventory or as otherwise may be reasonably satisfactory to the Collateral Agent. The Collateral Agent, at the expense of the Loan Parties, may participate in and/or observe each scheduled physical count of Inventory which is undertaken on behalf of any Loan Party. The Lead Borrower, within 30 days following the completion of such inventory, shall provide the Collateral Agent with a reconciliation of the results of such inventory (as well as of any other physical inventory or cycle counts undertaken by a Loan Party) and shall post such results to the Loan Parties’ stock ledgers and general ledgers, as applicable. (b) Permit the Collateral Agent, in its Permitted Discretion, if any Event of Default exists, to cause additional such inventories to be taken as the Collateral Agent determines (each, at the expense of the Loan Parties).

  • Recycled Products The Contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. References: 42 U.S.C. 6962, 40 CFR Part 247, Executive Order 12873 (More than $10,000)

  • Product Quality (a) Tesoro warrants that all Products delivered under this Agreement or any Purchaser Order shall meet the latest applicable pipeline specifications or otherwise mutually agreed upon specifications for that Product upon receipt at the applicable Terminal and contain no deleterious substances or concentrations of any contaminants that may make it or its components commercially unacceptable in general industry application. Tesoro shall not deliver to any of the Terminals any Products which: (i) would in any way be injurious to any of the Terminals; (ii) would render any of the Terminals unfit for the proper storage of similar Products; (iii) would contaminate or otherwise downgrade the quality of the Products stored in commingled storage; (iv) may not be lawfully stored at the Terminals; or (v) otherwise do not meet applicable Product specifications for such Product that are customary in the location of the Terminal. If, however, there are Products that do not have such applicable specifications, the specifications shall be mutually agreed upon by the Parties. Should Tesoro’s commingled Products not meet or exceed the minimum quality standards set forth in this Agreement or any applicable Terminal Service Order, Tesoro shall be liable for all loss, damage and cost incurred thereby, including damage to Products of third parties commingled with Tesoro’s unfit Products. (b) TLO shall have the right to store compatible Products received for Tesoro’s account with Products belonging to TLO or third parties in TLO’s commingled storage tanks. TLO shall handle Tesoro’s fungible Products in accordance with TLO’s prevailing practices and procedures for handling such Products. The quality of all Products tendered into commingled storage for Tesoro’s account shall be verified either by Tesoro’s refinery analysis or supplier’s certification, such that Products so tendered shall meet TLO’s Product specifications. All costs for such analysis shall be borne solely by Tesoro. TLO shall have the right to sample any Product tendered to the Terminals hereunder. The cost of such sampling shall be borne solely by TLO. All Products returned to Tesoro shall meet or exceed Product specifications in effect on the date the Products are delivered to Tesoro. Notwithstanding any other provision herein, any and all Products that leave the Terminals shall meet all relevant ASTM, EPA, federal and state specifications, and shall not leave the Terminals in the form of a sub-octane grade Product. (c) TLO shall exercise reasonable care to ensure that all Products delivered by third parties into commingled storage with Tesoro’s Products meet applicable Product specifications for such Product that are customary in the location of the Terminal. In the event that Tesoro’s Products are commingled with third-party Products that do not meet or exceed the minimum quality standards set forth in this Agreement or any Terminal Service Order, TLO shall be liable for all loss, damage and cost incurred thereby.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!