Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
12.3.1 Funding is not available;
12.3.2 Legal restrictions are placed upon the expenditure of monies for this category of service or supplies; or,
12.3.3 The Agency’s requirements in good faith change after award of the contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
CONTRACT EXHIBIT I PREFERRED PRICING AFFIDAVIT This preferred-pricing affidavit is entered into in accordance with section 216.0113, F.S., and as required by Contract No. 80101507-21-STC-ITSA (“Contract”) between (“Contractor”) and the Department of Management Services. As the person authorized by Contractor to sign this affidavit, I attest that the Contractor is in full compliance with the preferred-pricing clause of the Contract. Contractor’s Name: By: Signature Printed Name/Title Date: STATE OF COUNTY OF Sworn to (or affirmed) and subscribed before me this day of , by Vendor Name: FEIN# Vendor’s Authorized Representative Name and Title: Address: City, State, and Zip code: Phone Number: ( ) - E-mail: CORPORATE SEAL (IF APPLICABLE) (Print, Type, or Stamp Commissioned Name of Notary Public) [Check One] Personally Known OR Produced the following I.D.
Pricing Terms (1) All pricing in this Agreement as well as every Customer Product Agreement Extension refers to the price at which the Customer may Purchase the corresponding Parent Product. This is excluding taxes, surcharges or any other costs.
(2) Parent may at any time change the price of any Parent Product with reasonable notification to the Customer.
MINIMUM ORDER QUANTITY The State makes no commitment to purchase any minimum or maximum quantity, or dollar volume of products from the selected suppliers. Utilization of this agreement will be on an as needed basis by State Agencies and/or Cooperative Participants, Cities, Counties, Schools K-12, Colleges and Universities. The State will award to multiple suppliers; however, the State reserves the right to purchase like and similar products from other suppliers as necessary to meet operational requirements.
Extended Local Calling Scope Arrangement An arrangement that provides a Customer a local calling scope (Extended Area Service, “EAS”), outside of the Customer’s basic exchange serving area.
Commercial Price List Reductions Where NYS Net Prices are based on a discount from Contractor’s list prices, price decreases shall take effect automatically during the Contract term and apply to Purchase Orders submitted on or after the date Contractor lowers its pricing to its customers generally or to similarly situated government customers during the Contract term; or
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
