No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.
Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.
Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
EXTENSION OF USE The Contract may be extended to additional States or governmental jurisdictions upon mutual written agreement between New York State (the lead contracting State) and the Contractor. Political subdivisions and other authorized entities within each participating State or governmental jurisdiction may also participate in the Contract if such State normally allows participation by such entities. New York State reserves the right to negotiate additional minimum NYS Vehicle Discounts based on any increased volume generated by such extensions.
Suspension of Rules Relating to Recalcitrant Accounts The United States shall not require a Reporting [FATCA Partner] Financial Institution to withhold tax under section 1471 or 1472 of the U.S. Internal Revenue Code with respect to an account held by a recalcitrant account holder (as defined in section 1471(d)(6) of the U.S. Internal Revenue Code), or to close such account, if the U.S. Competent Authority receives the information set forth in paragraph 2 of Article 2 of this Agreement, subject to the provisions of Article 3 of this Agreement, with respect to such account.
Time Limit Extension The above mentioned time limits may be extended in individual cases, by the written consent of both Parties to this Agreement.
Extension of Probationary Period The probationary period shall not be extended except in the case of extended illness or injury or compelling personal situation during which time the employee was unable to work. In such cases, the probationary period may be extended for the length of time the ill or injured employee was unable to work.
