No Obstruction by Purchaser to Further Construction Sample Clauses

No Obstruction by Purchaser to Further Construction. The Purchaser understands and agrees that there may be further construction by addition of floor upon the existing Building with approval of KMC and upon integration of additional lands (Other Lands) to the Said Property as a part of the Said Complex and the Purchaser consents to the same and shall not obstruct or object to the same notwithstanding any inconvenience that may be suffered by the Purchaser due to and/or arising out of the said construction/development activity. The Purchaser also admits and accepts that the employees and/or agents and/or contractors of the Developer shall be entitled to use and utilize the Common Portions for movement of building materials and for other purposes and the Purchaser shall not raise any objection in any manner whatsoever with regard thereto.
Sample 1
AutoNDA by SimpleDocs
No Obstruction by Purchaser to Further Construction. Subject to compliance with Section 14 of the Act, the Promoter shall be entitled to construct further floors on and above the top roof of the Said Building and/or make other constructions elsewhere on the Said Complex and/or Said Project and the Purchaser shall not obstruct or object to the same notwithstanding any inconveniences that may be suffered by the Purchaser due to and arising out of the said construction/developmental activity. The Purchaser also admits and accepts that the Promoter and/or employees and/or agents and/or contractors of the Promoter shall be entitled to use and utilize the Common Areas for movement of building materials and for other purposes and the Purchaser shall not raise any objection in any manner whatsoever with regard thereto.
Sample 1
No Obstruction by Purchaser to Further Construction. The Developer and the Land Owners shall be entitled to construct further floor on and above the top roof of the Said Building and/or make other constructions elsewhere on the Said Property/Said Complex and/or extend the said project. For or relating to any such constructions, additions or alterations, etc., the Developer shall have the right to do all acts deeds and things and make all alterations and connections and to connect all existing utilities and facilities available at the Said Property to such addition or new extension as it deems expedient to use and enjoy the same and the Purchaser shall not obstruct or object to the same. The Purchaser also admits and accepts that the Developer and/or employees and/or agents and/or contractors of the Developer shall be entitled to use and utilize the Common Portions for movement of building materials and for other purposes and the Purchaser shall not raise any objection in any manner whatsoever with regard thereto.
Sample 1

Related to No Obstruction by Purchaser to Further Construction

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Waiver of Rule of Construction Each Party has had the opportunity to consult with counsel in connection with the review, drafting and negotiation of this Agreement. Accordingly, the rule of construction that any ambiguity in this Agreement shall be construed against the drafting Party shall not apply.

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Legal Construction If one or more of the provisions contained in this Agreement shall for any reason be held invalid, illegal, or unenforceable in any respect, such invalidity, illegality, or unenforceability shall not affect any other provisions and this Agreement shall be construed as if it did not contain the invalid, illegal, or unenforceable provision.

  • Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.

  • Conflict; Construction of Documents; Reliance In the event of any conflict between the provisions of this Agreement and any of the other Loan Documents, the provisions of this Agreement shall control. The parties hereto acknowledge that they were represented by competent counsel in connection with the negotiation, drafting and execution of the Loan Documents and that such Loan Documents shall not be subject to the principle of construing their meaning against the party which drafted same. Borrower acknowledges that, with respect to the Loan, Borrower shall rely solely on its own judgment and advisors in entering into the Loan without relying in any manner on any statements, representations or recommendations of Lender or any parent, subsidiary or Affiliate of Lender. Lender shall not be subject to any limitation whatsoever in the exercise of any rights or remedies available to it under any of the Loan Documents or any other agreements or instruments which govern the Loan by virtue of the ownership by it or any parent, subsidiary or Affiliate of Lender of any equity interest any of them may acquire in Borrower, and Borrower hereby irrevocably waives the right to raise any defense or take any action on the basis of the foregoing with respect to Lender’s exercise of any such rights or remedies. Borrower acknowledges that Lender engages in the business of real estate financings and other real estate transactions and investments which may be viewed as adverse to or competitive with the business of Borrower or its Affiliates.

  • Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!