Responsibility For Use (a) The Company alone will be responsible for furnishing, or arranging for a third party to furnish, all data and information required by the Documentation and the specifications therein for the Licensed System to function and perform in accordance with the Documentation, other than the data and information residing in the Licensed System in connection with BNYM’s performance of the Core Services. BNYM shall have no liability or responsibility for any Loss caused in whole or in part by the Company’s or a Permitted User’s exercise of the Licensed Rights or use of the Licensed System or by data or information of any nature inputted into the Licensed System by or under the direction or authorization of Company or a Permitted User; provided, however, this Section 2.5 shall not relieve BNYM of its obligation to act in accordance with its obligations under the Main Agreement. Company shall be responsible and solely liable for the cost or expense of regenerating any output or other remedial action if the Company, a Permitted User or an agent of either shall have failed to transmit properly and in the correct format any data or information, shall have transmitted erroneous or incorrect information or data, or shall have failed to timely verify or reconcile any such data or information when it is generated by the Licensed System (“Data Faults”).
No Responsibility Trustmark and the Trustmark Released Parties shall have no responsibility, obligation, duties, or liability whatsoever with respect to the terms, interpretation, or implementation of the Distribution Plan; the administration of the Settlement; the management, investment, or distribution of the Settlement Amount or any other funds paid or received in connection with the Settlement; the payment or withholding of Taxes that may be due or owing by the Receiver or any recipient of funds from the Settlement Amount; the determination, administration, calculation, review, or challenge of claims to the Settlement Amount, any portion of the Settlement Amount, or any other funds paid or received in connection with the Settlement or this Agreement; or any losses, attorneys’ fees, expenses, vendor payments, expert payments, or other costs incurred in connection with any of the foregoing matters. As of the Settlement Effective Date, the Plaintiffs, the Plaintiffs Released Parties, the Interested Parties, and all other individuals, Persons, or entities Plaintiffs represent or on whose behalf Plaintiffs have been empowered to act by any court fully, finally, and forever release, relinquish, and discharge Trustmark and the Trustmark Released Parties from any and all such responsibility, obligation, duties, and liability.
RESPONSIBILITY FOR EMPLOYEES To the extent that the Contract involves the provision of the Services to UNDP by the Contractor’s officials, employees, agents, servants, subcontractors and other representatives (collectively, the Contractor’s “personnel”), the following provisions shall apply: 8.1 The Contractor is responsible for and shall assume all risk and liabilities relating to its personnel and property. 8.2 The Contractor shall be responsible for the professional and technical competence of the personnel it assigns to perform work under the Contract and will select reliable and competent individuals who will be able to effectively perform the obligations under the Contract and who, while doing so, will respect the local laws and customs and conform to a high standard of moral and ethical conduct. 8.3 Such Contractor personnel shall be professionally qualified and, if required to work with officials or staff of UNDP, shall be able to do so effectively. The qualifications of any personnel whom the Contractor may assign or may propose to assign to perform any obligations under the Contract shall be substantially the same, or better, as the qualifications of any personnel originally proposed by the Contractor. 8.4 At the option of and in the sole discretion of UNDP: 8.4.1 the qualifications of personnel proposed by the Contractor (e.g., a curriculum vitae) may be reviewed by UNDP prior to such personnel’s performing any obligations under the Contract; 8.4.2 any personnel proposed by the Contractor to perform obligations under the Contract may be interviewed by qualified staff or officials of UNDP prior to such personnel’s performing any obligations under the Contract; and, 8.4.3 in cases in which, pursuant to Article 8.4.1 or 8.4.2, above, UNDP has reviewed the qualifications of such Contractor’s personnel, UNDP may reasonably refuse to accept any such personnel. 8.5 Requirements specified in the Contract regarding the number or qualifications of the Contractor’s personnel may change during the course of performance of the Contract. Any such change shall be made only following written notice of such proposed change and upon written agreement between the Parties regarding such change, subject to the following: 8.5.1 UNDP may, at any time, request, in writing, the withdrawal or replacement of any of the Contractor’s personnel, and such request shall not be unreasonably refused by the Contractor. 8.5.2 Any of the Contractor’s personnel assigned to perform obligations under the Contract shall not be withdrawn or replaced without the prior written consent of UNDP, which shall not be unreasonably withheld. 8.5.3 The withdrawal or replacement of the Contractor’s personnel shall be carried out as quickly as possible and in a manner that will not adversely affect the performance of obligations under the Contract. 8.5.4 All expenses related to the withdrawal or replacement of the Contractor’s personnel shall, in all cases, be borne exclusively by the Contractor. 8.5.5 Any request by UNDP for the withdrawal or replacement of the Contractor’s personnel shall not be considered to be a termination, in whole or in part, of the Contract, and UNDP shall not bear any liability in respect of such withdrawn or replaced personnel. 8.5.6 If a request for the withdrawal or replacement of the Contractor’s personnel is not based upon a default by or failure on the part of the Contractor to perform its obligations in accordance with the Contract, the misconduct of the personnel, or the inability of such personnel to reasonably work together with UNDP officials and staff, then the Contractor shall not be liable by reason of any such request for the withdrawal or replacement of the Contractor’s personnel for any delay in the performance by the Contractor of its obligations under the Contract that is substantially the result of such personnel’s being withdrawn or replaced. 8.6 Nothing in Articles 8.3, 8.4 and 8.5, above, shall be construed to create any obligations on the part of UNDP with respect to the Contractor’s personnel assigned to perform work under the Contract, and such personnel shall remain the sole responsibility of the Contractor. 8.7 The Contractor shall be responsible for requiring that all personnel assigned by it to perform any obligations under the Contract and who may have access to any premises or other property of UNDP shall: 8.7.1 undergo or comply with security screening requirements made known to the Contractor by UNDP, including but not limited to, a review of any criminal history; 8.7.2 when within UNDP premises or on UNDP property, display such identification as may be approved and furnished by UNDP security officials, and that upon the withdrawal or replacement of any such personnel or upon termination or completion of the Contract, such personnel shall immediately return any such identification to UNDP for cancellation. 8.8 Within one working day after learning that any of Contractor’s personnel who have access to any UNDP premises have been charged by law enforcement authorities with an offense other than a minor traffic offense, the Contractor shall provide written notice to inform UNDP about the particulars of the charges then known and shall continue to inform UNDP concerning all substantial developments regarding the disposition of such charges. 8.9 All operations of the Contractor, including without limitation, storage of equipment, materials, supplies and parts, within UNDP premises or on UNDP property shall be confined to areas authorized or approved by UNDP. The Contractor’s personnel shall not enter or pass through and shall not store or dispose of any of its equipment or materials in any areas within UNDP premises or on UNDP property without appropriate authorization from UNDP. 8.10 The Contractor shall (i) put in place an appropriate security plan and maintain the security plan, taking into account the security situation in the country where the Services are being provided; and
No Responsibility for Title, etc So long as and to the extent that it is in the exercise of reasonable care, the Custodian shall not be responsible for the title, validity or genuineness of any property or evidence of title thereto received or delivered by it pursuant to this Agreement.
Responsibility for Evaluation Within each school the Principal will be responsible for the evaluation of employees assigned to that school. Evaluation will be made by the Principal or a qualified administrator. An employee assigned to more than one school will be evaluated by the Principal of the school in which the employee is assigned for the greater amount of time, with input provided by the Principal of the other school. Any Principal or person charged with the responsibility of evaluation of employees may involve other staff and students in the process if acceptable to the certificated teacher being evaluated.
No Responsibility for Representations The Warrant Agent shall not be responsible for any of the recitals or representations herein or in the Warrant Certificates (except as to the Warrant Agent’s countersignature thereon), all of which are made solely by the Company.
IRO Responsibilities The IRO shall: 1. perform each Claims Review in accordance with the specific requirements of the CIA;
No Responsibility for Certain Matters No Agent shall be responsible to any Lender for the execution, effectiveness, genuineness, validity, enforceability, collectibility or sufficiency of this Agreement or any other Loan Document or for any representations, warranties, recitals or statements made herein or therein or made in any written or oral statements or in any financial or other statements, instruments, reports or certificates or any other documents furnished or made by such Agent to Lenders or by or on behalf of Company to such Agent or any Lender in connection with the Loan Documents and the transactions contemplated thereby or for the financial condition or business affairs of Company or any other Person liable for the payment of any Obligations, nor shall such Agent be required to ascertain or inquire as to the performance or observance of any of the terms, conditions, provisions, covenants or agreements contained in any of the Loan Documents or as to the use of the proceeds of the Loans or the use of the Letters of Credit or as to the existence or possible existence of any Event of Default or Potential Event of Default. Anything contained in this Agreement to the contrary notwithstanding, Administrative Agent shall not have any liability arising from confirmations of the amount of outstanding Loans or the Letter of Credit Usage or the component amounts thereof.
Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require. (b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price. (c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work. (d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.
Other Responsibilities The Responsibility factors also take account of any responsibility the jobholder may have through the provision of advice and guidance on policies and procedures, research or the adaptation or development of existing or new policies and procedures. An assessment tool has been developed to help ensure that advisory, policy and similar ‘hands off’ responsibilities, such as research or democratic services, are correctly measured and allocated to the appropriate Responsibility factor. It is recommended that jobs are first evaluated on their ‘hands on’ responsibilities under each Responsibility factor and that an assessment is then made of the level of advisory/policy responsibilities and the factor to which it should be allocated.
