No Termination or Suspension of Services (Continued Performance Sample Clauses

No Termination or Suspension of Services (Continued Performance. Notwithstanding anything to the contrary contained herein, and even if any dispute arises between the Parties or Subrecipient alleges the County’s breach of contract, and regardless of whether the Parties require at any time the use of any dispute resolution procedures in Paragraph 19 (Disputes – Contract) or otherwise established by the Parties in writing, or the exercise of Paragraph 72 (Set- Off), in no event nor for any reason shall Subrecipient, during the term of the Contract, suspend or otherwise interrupt the provision of services to the County or under this Contract, interrupt any obligations of or related to a Termination Transition Plan, disable any assets used to provide services, or perform any other action that prevents, impedes, or reduces in any way the provision of services or the County’s ability to conduct its activities, unless: (A) authority to do so is granted by the County’s Contract Administrator (or his or her designee) in writing or conferred by a court of competent jurisdiction; or, (B) the term of this Contract has expired, or been terminated pursuant to Paragraph K (Termination) hereof and Subrecipient has performed all services required to complete the Termination Transition Plan to the satisfaction of the County, and the Contract Administrator has provided written notice thereof.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
No Termination or Suspension of Services (Continued Performance. Notwithstanding anything to the contrary contained elsewhere herein, even if any Disagreement or other dispute arises between the Parties, and regardless of whether or not any such Disagreement or other dispute requires at any time the use of the dispute resolution procedures described above, in no event nor for any reason shall Vendor, at any time during the Term or during Disentanglement, halt, interrupt, or suspend the provision of Services to the County except for the duration of a valid Force Majeure Event.
Sample 1

Related to No Termination or Suspension of Services (Continued Performance

  • Suspension or Termination of Services You agree that Firstrade Securities Inc. reserves the right in its sole discretion to suspend or terminate your access to any or all of Firstrade Securities Inc.'s Electronic Services for any reason and without prior notice to you. You agree not to hold Firstrade Securities Inc. responsible or liable for any disruptions in service due to: telephone network, computer network or other system problems beyond the control of Firstrade Securities Inc.: system maintenance or system upgrades; or any other event or circumstance beyond the control of Firstrade Securities Inc.

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.

  • Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.

  • Suspension/Termination of account If your right to use the card is suspended or your card account is terminated, we may at our option and without prejudice to any of our rights and remedies, stop paying the said instalments for you, or bill the aggregate sum of the remaining instalments to you forthwith.

  • Suspension of Services We have the right to suspend the benefit of any Credit Union service at any time for reasonable cause. At Our discretion, We also have the right to pay any share draft presented for payment from Your Account after Your Account is closed or suspended and to recover such amount paid from You.

  • Suspension or Termination In accordance with 24 CFR 85.43, the Grantee may suspend or terminate this Agreement if the Recipient materially fails to comply with any terms of this Agreement, which include (but are not limited to), the following: 1. Failure to comply with any of the rules, regulations or provisions referred to herein, or such statutes, regulations, executive orders, and HUD guidelines, policies or directives as may become applicable at any time; 2. Failure, for any reason, of the Recipient to fulfill in a timely and proper manner its obligations under this Agreement; 3. Ineffective or improper use of funds provided under this Agreement; or 4. Submission by the Recipient to the Grantee reports that are incorrect or incomplete in any material respect. In accordance with 24 CFR 85.44, this Agreement may also be terminated for convenience by either the Grantee or the Recipient, in whole or in part, by setting forth the reasons for such termination, the effective date, and, in the case of partial termination, the portion to be terminated. However, if in the case of a partial termination, the Grantee determines that the remaining portion of the award will not accomplish the purpose for which the award was made, the Grantee may terminate the award in its entirety.

  • Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.

  • Termination of Service Relationship If the Optionee’s Service Relationship terminates, the period within which to exercise the Stock Option may be subject to earlier termination as set forth below.

  • Cessation of services The delegation or assignment of CONTRACTOR’s services, operation or administration to another entity without the prior written consent of COUNTY.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!