Non-Firm Expanded Imbalance MDQ. Despite anything to the contrary in this Agreement, and without limiting User's obligations, or Service Provider's rights, set out elsewhere in this Agreement:
Non-Firm Expanded Imbalance MDQ Sample Clauses
Related to Non-Firm Expanded Imbalance MDQ
Project Specific Milestones In addition to the milestones stated in Section 212.5 of the Tariff, as applicable, during the term of this ISA, Interconnection Customer shall ensure that it meets each of the following development milestones:
Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
First Year Wage Adjustment Effective July 1, 2017, all salary ranges and rates shall be increased by two percent (2.0%), rounded to the nearest cent. The compensation grids for classes covered by this Agreement are contained in Appendix E-1. Employees shall convert to the new compensation grid as provided in Section 2.
CPI Adjustment In this Agreement, “CPI-Adjusted” in reference to an amount means that amount is adjusted under the following formula: N C (1 CPIn CPIc ) CPIc where: ”N” is the new amount being calculated; and “C” is the current amount being adjusted; and
Contract Term Adjustment “Contract Term Adjustment” means adjustment only as provided for in the three circumstances described in this Subsection. Under these circumstances, the contract term shall be adjusted in writing to include additional calendar days in one or more Normal Operating Seasons equal to the actual time lost, except as limited by paragraph (b) in this Subsection. To qualify for such adjustment, Purchaser shall give written notice of the lost time not later than 30 days after end of Normal Operating Season in which time was lost and at least 10 days before Termination Date. Contracting Officer shall make prompt written acknowledgment of such notice, indicating concurrence with the number of days in the notice or the number of days Forest Service considers as qualifying for the adjustment. Lost portions of days shall be disregarded in computing time lost. The three circumstances qualifying for a Contract Term Adjustment are:
Milestone schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.
Rental Rates and Wage Rates for Change Orders As soon as is practical, but prior to the completion of the Construction Preparation Period and in any event prior to the commencement of any Work on the Site, the Contractor shall submit in accordance with the style and format of a specimen to be furnished by the Owner for consideration of the Owner the following: (1) a proposal for rental rates on heavy construction equipment that shall apply in the event Change Order Work is performed, and (2) a proposal for wage rates for the types of project labor that shall apply in the event of the execution of any Change Order Work. Under penalty of false swearing, a principal of the contracting firm shall certify that the proposal for rental rates and proposal for wage rates do not exceed current costs for like services. The Owner will in no event consider a rental rate in excess of eighty percent of the rate set forth in the latest edition of the "Compilation of Nationally Averaged Rental Rates for Construction Equipment" of the Associated Equipment Distributors unless the rates proposed in excess of eighty percent are supported by proof satisfactory to the Owner that the excess rates are reasonable. If the equipment is owned by the Contractor the costs shall be charged at a maximum of eighty percent of market monthly rental rates for the amount of time used. If applicable, transportation costs may be included. The decision of the Owner shall be final, binding and conclusive on all parties. Rental rates shall be payable only for the actual time the equipment is required on the Site.
Cost of Living Adjustment For each year following the Initial Term, unless the parties shall otherwise agree and provided that the service mix and volumes remain consistent as previously provided in the Initial Term, the total fee for all services shall equal the fee that would be charged for the same services based on a fee rate (as reflected in a fee rate schedule) increased by the percentage increase for the twelve-month period of such previous calendar year of the CPI-W (defined below) or, in the event that publication of such index is terminated, any successor or substitute index, appropriately adjusted, acceptable to both parties. As used herein, “CPI-W” shall mean the Consumer Price Index for Urban Wage Earners and Clerical Workers (Area: Boston-Brockton-Nashua, MA-NH-ME-CT; Base Period: 1982-84=100), as published by the United States Department of Labor, Bureau of Labor Statistics.
Contingent Price Adjustment It is the policy of the State of Oregon that unprocessed timber shall not be exported from lands owned or managed by the STATE or any of its political subdivisions or agencies, in accordance with the terms of current federal law and the Constitution and the laws of the State of Oregon. PURCHASER specifically agrees that Section 1 is a material term of this contract and is part of the consideration offered to STATE in return for STATE's performance. In the event that any federal law or state constitutional provision or law or any provision of this contract concerning export of unprocessed timber is declared invalid by any court or administrative tribunal, PURCHASER agrees to pay to STATE a contingent price in the amount of the difference between the purchase price set forth in this section and the price obtained by PURCHASER for the exported unprocessed timber. The default provisions of OAR 629-032-0000 through 629-032-0070 shall not apply to exported unprocessed timber. In the event that timber made available under this contract is exported in violation of this contract, PURCHASER shall be in material breach of the contract. STATE shall be entitled to cease performance of the contract and recover, in addition to the adjusted price set out above, a further sum estimated to compensate for administrative expense and the economic impact of the violation upon the State and its citizens. In no case shall this additional amount be less than $10,000 per incident.
Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
