Separate Contractor Any person or entity other than Contractor that enters into an agreement with Owner to perform the construction of all or any portion of the construction on a Project.
Contractor’s Employees Contractor may, in its discretion and at its own expense, employ such assistants as Contractor deems necessary to perform the Services. If any specific employee is designated in Schedule 1 to perform the Services, Contractor may only replace such designated employee with SMUD’s prior written approval, and with a replacement satisfactory to SMUD. SMUD may not control, direct, or supervise Contractor or Contractor’s Representatives in the performance of the Services. Contractor agrees to assume full responsibility for the payment and deduction of all state and federal taxes and benefits from Contractor’s Representatives, including but not limited to any applicable payroll and income taxes, unemployment insurance, disability insurance, retirement, workers’ compensation, pension, or other social security benefits for all persons or entities employed or retained by Contractor in the performance of the Services under this Agreement, and if applicable for all self-employment and other taxes incurred by Contractor in the performance of the Services.
Agreements with Employees and Subcontractors Grantee shall have written, binding agreements with its employees and subcontractors that include provisions sufficient to give effect to and enable Grantee’s compliance with Grantee’s obligations under this Article VI, Intellectual Property.
Stock Plan Administration Service Providers The Company transfers participant data to Xxxxxx Xxxxxxx, an independent service provider based in the United States, which assists the Company with the implementation, administration and management of the Plan. In the future, the Company may select a different service provider and share the Participant’s data with another company that serves in a similar manner. The Company’s service provider will open an account for the Participant to receive and trade Shares. The Participant will be asked to agree on separate terms and data processing practices with the service provider, which is a condition to the Participant’s ability to participate in the Plan.
EMPLOYER AND UNION TO ACQUAINT NEW EMPLOYEES (a) At the time of hire new employees will be advised that a collective agreement is in effect and of the conditions of employment set out in the articles dealing with Union Security and Dues Check-off. (b) A new employee shall also be provided with: (1) the name, location and work telephone number of the xxxxxxx; and (2) an authorization form for union dues check-off. (c) Upon request, the xxxxxxx shall be advised of the name, location and work telephone number of the new employee. (d) The xxxxxxx will be given an opportunity to interview each new employee within regular working hours, without loss of pay, for 15 minutes sometime during the first 30 days of employment. (e) The Union will provide the Employer with an up-to-date list of stewards' names, work locations and work telephone numbers in order that the Employer may meet its obligation in (b)(1) above. (f) The Union will be provided with a copy of the completed and signed authorization form for dues check-off for all new employees.
Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA. (b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA. (c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein. (d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors. (e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.
Contractor and Employee Security Precautions The security aspects of working at the Correctional Facility are critical. The following security precautions are part of the site conditions and are a part of this Contract. All persons coming on the site in any way connected with this Work shall be made aware of them, and it is the (General) Contractor’s responsibility to check and enforce them.
Separate Contracts The Owner reserves the right at any time and from time to time upon notice to Contractor to perform, or cause to be performed by other Contractors, other work at the Site in connection with the development of the Project that is not contemplated hereby or that is contemplated hereby if the Contractor and the Owner shall be unable to agree upon a Change Order incorporating such work as Work of the Contractor under this Contract. In either case, the Owner shall assure that such personnel or Contractors do not cause any conflict with the Work of Contractor. Contractor shall afford the Owner and other Contractors reasonable opportunity for the introduction, protection, and storage of material and equipment at the Site and the execution of work, and shall properly connect, if required by Contract Documents, and coordinate its work with theirs. If any work by the Owner or its other Contractors increases Contractor's costs or extends the time of performance, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable costs actually incurred by Contractor as a result thereof and to an extension of time for performance for such reasonable time as the Design Professional shall determine. Contractor has no responsibility hereunder to certify the suitability or correctness of any work performed by Owner's own personnel or other Contractors under direct contract with the Owner. This Article also applies to installation of loose equipment and fixtures by the Owner, Using Agency, or a Separate Contractor.
Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
Coordination, Oversight and Monitoring of Service Providers As set forth in the Administrative Services Agreement between the Fund and CRMC, CRMC shall coordinate, monitor and oversee the activities performed by the Service Providers with which AFS contracts. AFS shall monitor Service Providers’ provision of services including the delivery of Customer account statements and all Fund-related material, including summary prospectuses and/or prospectuses, shareholder reports, and proxies.
