Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Co-operation The Custodian shall cooperate with and supply necessary information to the entity or entities appointed by the Trust to keep the books of account of the Fund and/or compute the value of the assets of the Fund. The Custodian shall take all such reasonable actions as the Trust may from time to time request to enable the Trust to obtain, from year to year, favorable opinions from the Trust's independent accountants with respect to the Custodian's activities hereunder in connection with (a) the preparation of the Trust's reports on Form N-1A and Form N-SAR and any other reports required by the Securities and Exchange Commission, and (b) the fulfillment by the Trust of any other requirements of the Securities and Exchange Commission.
Maximum Annual Operating Expense Limit The Maximum Annual Operating Expense Limit with respect to each Fund shall be the amount specified in Schedule A based on a percentage of the average daily net assets of each Fund.
Lawful Operations, etc Each Credit Party and each of its Subsidiaries: (i) holds all necessary foreign, federal, state, provincial, local and other governmental licenses, registrations, certifications, permits and authorizations necessary to conduct its business and own its properties; and (ii) is in full compliance with all requirements imposed by law, regulation or rule, whether foreign, federal, state or local, that are applicable to it, its operations, or its properties and assets, including, without limitation, applicable requirements of Environmental Laws, except for any failure to obtain and maintain in effect, or noncompliance that, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect.
Annual Operating Plan Manager shall implement the Operating Plan prepared by Owner. The Operating Plan shall constitute a standard to which Manager shall reasonably attempt to adhere in the operation of the Project; provided, however, as the Operating Plan is a budget, Manager makes no representation or warranty that the actual operations of the Project shall conform to such plan. Except in an emergency, Manager shall not expend funds in any fiscal year in excess of the budgeted line item amounts in the Operating Budget without Owner's prior written approval. In the event any Fiscal Year shall commence without an approved Operating Plan, until the Operating Plan for such Fiscal Year is approved, Manager shall be entitled to make expenditures for items specified in the approved Operating Plan for the past Fiscal Year, at a rate not in excess of the rate permitted under that prior Operating Plan (other than for utilities, taxes, insurance premiums and mortgage payments), without the prior consent of Owner.
Annual Operating Budget As soon as available but, in any event, within sixty (60) days prior to (i) the Cooperation Period Commencement Date in respect of the initial Plant to be completed and, thereafter, (ii) the commencement of each Fiscal Year, an annual operating budget (the "Annual Budget") (including budgeted statements of income and sources and uses of cash and balance sheets) prepared by the Borrower and accompanied by a statement of the chief financial officer of the Borrower to the effect that, the best of his or her knowledge, the budget is a reasonable estimate for the period covered thereby. The first Annual Budget shall cover the period from the Cooperation Period Commencement Date through the end of the Fiscal Year in which the Cooperation Period Commencement Date occurs, and, if such period consists of less than six (6) months, for the immediately succeeding Fiscal Year. Each Annual Budget shall contain complete, fair and accurate estimates (by principal components) of Sales Proceeds, Operating and Maintenance Costs and Debt Service for each Month covered by such Annual Budget based on the Borrower's best projections at such time. Unless otherwise consented to by Eximbank, the Annual Budget from year to year shall be based on the same format as the Base Case Forecast, including any amounts allocated for contingencies, and be maintained on the same basis and provide sufficient detail to permit a meaningful comparison. For each Annual Budget that is expected to cover any period occurring after the Disbursement Date, Eximbank (in consultation with the Independent Engineer) shall review such Annual Budget, and Eximbank's response shall not be unreasonably delayed. If Eximbank does not approve an Annual Budget, Eximbank shall notify the Borrower of the items which are disapproved and the reason for such disapproval. Until such Annual Budget is so approved, the Annual Budget most recently in effect shall continue to apply, except that any items of the then proposed Annual Budget that have been approved shall also be given effect. From time to time, but not more frequently than once per Quarter, the Borrower may propose amendments to an Annual Budget, and Eximbank (in consultation with the Independent Engineer) may reject such proposal within thirty (30) Business Days from the date the Borrower submits such proposal if in Eximbank's reasonable judgment such amendment is not reasonably necessary or advisable for operation of the Project and, if no such rejection is made, such amendments shall become effective. Not later than three (3) Business Days after the effective date of each Annual budget and of any amendment thereto, the Borrower shall provide a copy of the same to the Collateral Trustee.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Total Operating Expenses All costs and expenses paid or incurred by the Company, as determined under GAAP, that are in any way related to the operation of the Company or its business, including the Advisory Fee, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and taxes incurred in connection with the issuance, distribution, transfer and registration of securities, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines; (vi) acquisition fees and Acquisition Expenses, (vii) real estate commissions on the sale of Real Property, and (viii) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgages or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair, and improvement of property). The definition of “Total Operating Expenses” set forth above is intended to encompass only those expenses which are required to be treated as Total Operating Expenses under the NASAA REIT Guidelines. As a result, and notwithstanding the definition set forth above, any expense of the Company which is not part of Total Operating Expenses under the NASAA REIT Guidelines shall not be treated as part of Total Operating Expenses for purposes hereof. 2%/25% Guidelines. 2%/25% Guidelines shall have the meaning set forth in Section 14.
Maintenance and Operation (a) Lessee, at its own cost and expense, shall maintain, repair and keep each Unit, and cause the Manager under the Management Agreement to maintain, repair and keep each Unit, (i) according to Prudent Industry Practice and in all material respects, in good working order, and in good physical condition for railcars of a similar age and usage, normal wear and tear excepted, (ii) in a manner in all material respects consistent with maintenance practices used by the Manager in respect of railcars owned, leased or managed by the Manager similar in type to such Unit or, with respect to (A) any Equipment subject to an Existing Equipment Sublease that is a Net Sublease, maintenance practices used by the applicable Sublessee in respect of railcars similar in type to such Unit used by such Sublessee on its domestic routes in the United States; (provided further, however that after the return to the Manager of any Unit which was subject to a Net Sublease immediately prior to such return, such Unit shall be maintained and repaired in all material respects in a manner consistent with maintenance practices used by the Manager in respect of railcars owned, leased or managed by the Manager similar in type to such Unit) and (B) any Permitted Sublease that is a Net Sublease entered into after the Closing Date where (x) the long term unsecured debt of the applicable Sublessee is rated at least BBB- by S&P and Baa3 by Xxxxx'x (or at least BBB- by S&P or Baa3 by Xxxxx'x if then rated by only one such rating agency) or similarly rated by any rating agency, (y) the applicable Sublessee is organized under the laws of the United States or any State thereof and (z) the applicable Sublessee is the owner or lessee of at least 250 railcars used primarily on domestic routes in the United States, maintenance practices used by such Sublessee in respect of railcars similar in type to such Unit, (iii) in accordance with all manufacturer's warranties in effect but only to the extent that the lack of compliance therewith would reasonably be expected to adversely affect the coverage thereunder and in accordance with all applicable provisions, if any, of insurance policies required to be maintained pursuant to Section 12 and (iv) in compliance in all material respects with any applicable laws and regulations from time to time in effect, including, without limitation, the Field Manual of the AAR, FRA rules and regulations and Interchange Rules as they apply to the maintenance and operation of the Units in interchange regardless of upon whom such applicable laws and regulations are nominally imposed; provided, however, that, so long as the Manager or, with respect to any Equipment subject to an Existing Equipment Sublease which is a Net Sublease, the applicable Sublessee, as applicable, is similarly contesting such law or regulation with respect to all other similar equipment owned or operated by Manager or, with respect to any Equipment subject to an Existing Equipment Sublease which is a Net Sublease, the applicable Sublessee, as applicable, Lessee (or such Sublessee) may, in good faith and by appropriate proceedings diligently conducted, contest the validity or application of any such standard, rule or regulation in any manner that does not (w) materially interfere with the use, possession, operation or return of any of the Units, (x) materially adversely affect the rights or interests of Lessor, Policy Provider or the Indenture Trustee in the Units or hereunder, (y) expose Lessor, Policy Provider or the Indenture Trustee to criminal sanctions or (z) violate any maintenance requirements contained in any insurance policy required to be maintained by the Lessee under this Lease or the Collateral Agency Agreement if such violation would reasonably be expected to adversely affect the coverage thereunder; provided further, that Lessee shall promptly notify Lessor, Policy Provider and Indenture Trustee in reasonable detail of any such contest. In no event shall Lessee discriminate in any material respect as to the use or maintenance of any Unit (including the periodicity of maintenance or recordkeeping in respect of such Unit) as compared to equipment of a similar nature which the Manager owns or manages. Lessee will maintain all records, logs and other materials required by relevant industry standards or any governmental authority having jurisdiction over the Units required to be maintained in respect of any Unit, all as if Lessee were the owner of such Units, regardless of whether any such requirements, by their terms, are nominally imposed on Lessee, Lessor or Owner Participant.
General Operations Tenant covenants and agrees to furnish to Landlord, promptly upon request of Landlord, copies of:
