Notice of Complaint / Claim Procedure. The Parties shall comply with the complaint procedures as agreed upon in the Supplier QHSE Requirements Manual.
Notice of Complaint / Claim Procedure Sample Clauses
Related to Notice of Complaint / Claim Procedure
Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.
Notice of Litigation Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any Proceedings or threatened Proceedings concerning any Serviced Appointment, in each case, excluding Proceedings in servicer-managed mortgage-level litigation with respect to residential mortgage-backed securities transactions. Notices delivered pursuant to this Section 5.4 will be delivered to the notice recipient designated on Annex B.
Complaints Procedure 18.1 If the Client has any cause for complaint in relation to the services provided by the Company, he should file a complaint as per the Company’s Complaint Handling policy which is available on the Company’s website.
Complaint Procedure If an employee has a complaint, which is not a proper subject for a grievance under the grievance procedure, the employee may discuss it with their immediate supervisor. The employee may submit the complaint in writing. If necessary, the employee may also discuss the complaint with the Director of Staff Relations. The employee may have the assistance of their Alliance representative in presenting the complaint. Complaints shall be answered as soon as reasonably possible, but in no event shall an answer be delayed more than seven (7) business days, unless the time for an answer is extended by mutual agreement. If the employee and the Alliance are dissatisfied with the answer they may request a Special Conference.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
CLAIM PROCEDURES Claim forms or claim information as to the subject policy can be obtained by contacting Benmark, Inc. (800-544-6079). When the Named Fiduciary has a claim which may be covered under the provisions described in the insurance policy, they should contact the office named above, and they will either complete a claim form and forward it to an authorized representative of the Insurer or advise the named Fiduciary what further requirements are necessary. The Insurer will evaluate and make a decision as to payment. If the claim is payable, a benefit check will be issued in accordance with the terms of this Agreement. In the event that a claim is not eligible under the policy, the Insurer will notify the Named Fiduciary of the denial pursuant to the requirements under the terms of the policy. If the Named Fiduciary is dissatisfied with the denial of the claim and wishes to contest such claim denial, they should contact the office named above and they will assist in making an inquiry to the Insurer. All objections to the Insurer's actions should be in writing and submitted to the office named above for transmittal to the Insurer.
Notice of Disputes Notice of the dispute will be submitted on the form provided in Appendix A and sent to the responding party, in order to provide an opportunity to respond. The Crown shall be provided with a copy.
DISPUTE PROCEDURE (1) Unless otherwise provided in the Council's Constitution or in this Collective Agreement, any dispute within the registered scope of the Council shall be resolved as set out below:
Notice of Dispute The party wishing to commence the dispute resolution process must give written notice (Notice of Dispute) to the other parties of:
Review Procedure If the Plan Administrator denies part or all of the claim, the claimant shall have the opportunity for a full and fair review by the Plan Administrator of the denial, as follows:
