Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Notice of Direct Claims Any claim for indemnification or contribution under this Agreement or any Ancillary Agreement that does not result from a Third-Party Claim shall be asserted by written notice given by the Indemnitee to the applicable Indemnifying Party; provided, that the failure by an Indemnitee to so assert any such claim shall not prejudice the ability of the Indemnitee to do so at a later time except to the extent (if any) that the Indemnifying Party is prejudiced thereby. Such Indemnifying Party shall have a period of thirty (30) days after the receipt of such notice within which to respond thereto. If such Indemnifying Party does not respond within such thirty (30)-day period, such specified claim shall be conclusively deemed a Liability of the Indemnifying Party under this Section 4.6(b) or, in the case of any written notice in which the amount of the claim (or any portion thereof) is estimated, on such later date when the amount of the claim (or such portion thereof) becomes finally determined. If such Indemnifying Party does not respond within such thirty (30)-day period or rejects such claim in whole or in part, such Indemnitee shall, subject to the provisions of Article VII, be free to pursue such remedies as may be available to such party as contemplated by this Agreement and the Ancillary Agreements, as applicable, without prejudice to its continuing rights to pursue indemnification or contribution hereunder.
Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.
NOTICE OF INJURIES If Tenant or any of Tenant's invitees, licensees, and/or guests are significantly injured or any of Tenant's personal property is damaged on the Property or in any common area, Tenant shall provide written notice to Landlord, to be delivered or sent to the address where Rent payments are sent, as soon as possible but in no event later than 5 (five) days after the date of injury or damage. If Tenant does not provide such timely notice, this shall be considered a breach of the Lease.
NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
Notice of Appeal In the event that an employee who has been laid off out of seniority order believes the decision based upon performance and/or qualifications is incorrect, the employee may request that the Association appeal the Sheriff’s determination. If the Association finds there is good reason to believe that the Sheriff has erred in his decision, it may appeal through the process set forth in this Article. Such appeal shall be filed within five (5) working days of delivery of the layoff notice to the employee.
Notice of Complaints Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any complaint concerning any Serviced Appointment made by any party to the Serviced Corporate Trust Contracts, any Securityholder, any Credit Enhancement Provider or any rating agency.
Notice of Actions Tenant will notify Landlord of any of the following actions affecting Landlord, Tenant or the Premises or the Project that result from or in any way relate to Tenant’s use of the Premises or the Project immediately after receiving notice of the same: (i) any enforcement, cleanup, removal or other governmental or regulatory action instituted, completed or threatened under any Hazardous Materials Law; (ii) any claim made or threatened by any person relating to damage, contribution, liability, cost recovery, compensation, loss or injury resulting from or claimed to result from any Hazardous Material; and (iii) any reports made by any person, including Tenant, to any environmental agency relating to any Hazardous Material, including any complaints, notices, warnings or asserted violations. Tenant will also deliver to Landlord, as promptly as possible and in any event within five (5) business days after Tenant first receives or sends the same, copies of all claims, reports, complaints, notices, warnings or asserted violations relating in any way to the Premises or the Project or Tenant’s use of the Premises or the Project. Upon Landlord’s written request, Tenant will promptly deliver to Landlord documentation acceptable to Landlord reflecting the legal and proper disposal of all Hazardous Materials removed or to be removed from the Premises. All such documentation will list Tenant or its agent as a responsible party and the generator of such Hazardous Materials and will not attribute responsibility for any such Hazardous Materials to Landlord or Landlord’s property manager.
Notice of Third Party Claims Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.
Notice of Action When a supervisor or manager believes it is necessary to impose a minor disciplinary action on an employee, the supervisor shall notify the employee in writing of his/her decision stating the reason for the action, the regulations or rules which have been violated, the specific action to be taken, and the effective date of the action.
