NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
NOTICE OF LABOR DISPUTES. When an actual or potential labor dispute or other condition delays or threatens to delay the timely performance of this Order, Seller shall immediately notify Buyer in writing. Such notice shall include all relevant information regarding such dispute or other condition. Seller shall insert the essence of this provision in all subcontracts issued hereunder.
NOTICE OF LABOR DISPUTES. Whenever an actual or potential labor dispute is delaying or threatens to delay the timely performance of this Order, Seller shall immediately give notice thereof, including all relevant information with respect thereto, to Buyer. Any subcontract hereunder as to which a labor dispute may delay the timely performance of this Order, shall provide that in the event its timely performance is delayed or threatened to be delayed by any actual or potential labor dispute, the subcontractor shall immediately notify Seller of all relevant information with respect to such dispute.
NOTICE OF LABOR DISPUTES. Whenever any actual or potential labor dispute delays or threatens to delay the timely performance of this order, Seller shall immediately give notice thereof to Buyer.
NOTICE OF LABOR DISPUTES. Whenever Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the time of performance of this contract, Contractor shall immediately give notice thereof, including all relevant information with respect thereto, to County.
NOTICE OF LABOR DISPUTES. Whenever an actual or potential labor dispute, or any government embargo or regulatory or tribunal proceedings relating thereto, is delaying or threatens to delay the timely performance of the Agreement, Supplier will immediately notify Applied of such dispute and furnish all relevant details, regardless of whether said dispute arose directly or indirectly as a result of an actual or potential dispute within the Supplier's sub-tier supply base or Supplier's own operations.
NOTICE OF LABOR DISPUTES. When an actual or potential labor dispute or other condition delays or threatens to delay the timely performance of this Agreement, Seller shall immediately notify BATTELLE in writing. Such notice shall include all relevant information regarding such dispute or other condition. Seller shall insert the essence of this provision in all lower-tier procurements issued hereunder.
NOTICE OF LABOR DISPUTES. Whenever an actual or potential labor dispute is delaying or threatens to delay the timely performance of this Purchase Order, Seller will immediately notify Buyer of such dispute and furnish all relevant details.
NOTICE OF LABOR DISPUTES. If RPTA has knowledge of any actual or threatened labor dispute that is delaying or threatens to delay the timely or proper performance of this Agreement, RPTA shall immediately give Tempe Notice of this dispute, including all relevant information.
NOTICE OF LABOR DISPUTES. 1. Whenever the Design-Builder has knowledge that any actual or potential labor disputes is delaying or threatens to delay the timely performance of this Contract, the Design-Builder must immediately give notice to the Commission Representative in accordance with the Notice provision of Section 22.05 and must include all available information with respect thereto to the Commission.
