Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.
TENANT'S HOLD OVER If Tenant remains in possession of the Premises with the consent of Landlord after the natural expiration of this Agreement, a new tenancy from month-to-month shall be created between Landlord and Tenant which shall be subject to all of the terms and conditions hereof except that rent shall then be due and owing at DOLLARS ($ ) per month and except that such tenancy shall be terminable upon thirty (30) days written notice served by either party.
Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Subleases of Tenant Whether or not Landlord elects to terminate this Lease on account of any default by Tenant, as set forth in this Article 19, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlord’s sole discretion, succeed to Tenant’s interest in such subleases, licenses, concessions or arrangements. In the event of Landlord’s election to succeed to Tenant’s interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.
RIGHT OF LANDLORD TO PERFORM All covenants and agreements to be performed by Tenant under any of the terms of this Lease shall be performed by Tenant at Tenant's sole cost and expense and without any abatement of rent. If Tenant shall fail to pay any sum of money, other than rent, required to be paid by it hereunder or shall fail to perform any other act on its part to be performed hereunder, and such failure shall continue beyond any applicable cure period set forth in this Lease, Landlord may, but shall not be obligated to, without waiving or releasing Tenant from any obligations of Tenant, make any such payment or perform any such other act on Tenant's part to be made or performed as is in this Lease provided. All sums so paid by Landlord and all reasonable incidental costs, together with interest thereon at the rate of ten percent (10%) per annum from the date of such payment by Landlord, shall be payable to Landlord on demand and Tenant covenants to pay any such sums, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the nonpayment thereof by Tenant as in the case of default by Tenant in the payment of the rent.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Assignment and Subletting by Tenant Tenant may not assign its interest in this Lease or sublet the whole or any part of the Premises without the prior consent of Landlord, which consent will not be unreasonably withheld, delayed or conditioned. Tenant shall remain primarily liable and responsible under this Lease in the event of any such assignment or sublease and shall not be released from its obligations hereunder nor shall the guaranty of the Lease by Air Industries Group be terminated or released. Any assignment of this Lease or subletting of the Premises without notification to and consent by Landlord shall not be effective as to Landlord and Landlord shall not be bound thereby. Tenant agrees that it shall not be unreasonable for Landlord to withhold its consent to a proposed sublease or assignment if: (a) The proposed assignee (“Proposed Assignee”) refuses to provide Landlord with financial statements covering a period of at least 12 months ending no earlier than six months and no later than three months prior to the effective date of the proposed assignment; (b) The Proposed Assignee shall not agree in writing to assume all of the obligations of Tenant under this Lease from and after the date of assignment; (c) Tenant or Proposed Assignee shall fail to pay to Landlord a processing fee of One Thousand Five Hundred ($1,500.00) Dollars (increased by 2% each year commencing 1/1/17) in connection with the proposed sublet or assignment of this lease; (d) Tenant shall fail to furnish Landlord with a true and correct copy of the sublease or assignment and assumption not less than thirty (30) days prior to execution for Landlord’s review and approval and a fully executed counterpart of the sublease or assignment and assumption of this Lease, as applicable, within ten (10) days after the date of the execution of same; (e) The Proposed Assignee is not solvent or is generally held in disrepute; (f) Without consent of Landlord, Tenant may assign this Lease to a corporation or other entity which is a direct or indirect subsidiary of Guarantor. (g) Without consent of Landlord Tenant may assign this Lease or the holders of the equity interests of Tenant may sell or assign such interests to a third party which acquires all or substantially all of the business then being conducted by Tenant at the Premises. (h) Without consent of Landlord, Tenant may sell or transfer a minority of its equity interests or otherwise assign or sublease to an affiliate or subsidiary of Tenant or its parent company; up to forty-nine percent (49%) of the Premises, or transfer equity interests in connection with going public. (i) Under no circumstances shall Tenant or Guarantor be released from any liability under this Lease or Guaranty.
