Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Term and Survival a) Subject to earlier termination as provided below, this Service Agreement is for the total duration of the Company’s Offering (the “Initial Term”) unless either party requests termination at least 30 days prior to the end of the then-current term.
b) Additionally, either party may terminate this Service Agreement in the event:
i) The other party’s material breach that remains not cured and continues for a period of (A) in the case of a failure involving the payment of any undisputed amount due hereunder, 15 days and (B) in the case of any other failure, 30 days after the non performing party receives notice from the terminating party specifying such failure;
ii) Any statement, representation or warranty of the other party is untrue or misleading in any material respect or omits material information;
iii) The other party (A) voluntarily or involuntarily is subject to bankruptcy proceedings, (B) applies for or consents to the appointment of a receiver, trustee, custodian, sequestrator, or similar official, (C) makes a general assignment to creditors, (D) commences winding down or liquidation of its business affairs, (E) otherwise takes corporate action for the purpose of effecting any of the foregoing, or (F) ceases operating in the normal course of business;
iv) If any change to, enactment of, or change in interpretation or enforcement of any law occurs that would have a material adverse effect upon a party’s ability to perform its obligations under this Service Agreement or a party’s costs/revenues with respect to the services under this Service Agreement;
v) Upon direction to a party from any regulatory authority or National Automated Clearing House Association to cease or materially limit the exercise or performance of such party’s rights or obligations under this Service Agreement;
vi) If there shall have occurred a material adverse change in the financial condition of the other party; or
vii) Upon a force majeure event that materially prevents or impedes a party from performing its obligations hereunder for a period of more than 10 business days.
