NPC INDEMNIFY Sample Clauses

NPC INDEMNIFY. NPC shall indemnify and hold CEPA, its officers and employees harmless against any claims of any person who directly or indirectly suffers as a result of an interruption of electricity supply or any other disruption or surge of electricity supply arising out of or in connection with this Agreement and any of CEPA's officers or employees' actions or omissions in connection with the same and NPC shall indemnify CEPA against any loss, cost or expense resulting from damage to the Power Station caused or resulting from any interruption or disruption or surge of electricity along the Transmission Line, unless and to the extent that such loss, cost or expense would have been avoided had any safety and protective equipment installed on the Site by CEPA not failed to operate according to specifications agreed between NPC and CEPA.
Sample 1
AutoNDA by SimpleDocs

Related to NPC INDEMNIFY

  • TO HOLD HARMLESS AND INDEMNIFY THE RELEASEES from any and all liability for any damage to property of or personal injury to any third party, resulting from my use of the Equipment;

  • Indemnify The Association agrees to indemnify and hold the City harmless against any and all claims, suits, orders or judgments brought or issued against the Association as a result of any action taken or not taken by the Association with respect to authorized deductions for coverage in excess of that provided in Section 3 of this Article.

  • HOLD HARMLESS/INDEMNIFICATION Contractor agrees to protect, defend, and save State, its elected and appointed officials, agents, and employees, while acting within the scope of their duties as such, harmless from and against all claims, demands, causes of action of any kind or character, including the cost of defense thereof, arising in favor of Contractor's employees or third parties on account of bodily or personal injuries, death, or damage to property arising out of services performed or omissions of services or in any way resulting from the acts or omissions of Contractor and/or its agents, employees, representatives, assigns, subcontractors, except the sole negligence of State, under this Contract.

  • The Indemnified Person (a) shall give the Indemnifying Party notice of the Claim promptly after becoming aware thereof (including a statement of facts known to the Indemnified Person related to the Claim and an estimate of the amount thereof); (b) prior to taking any material action with respect to a Third Party Claim, shall consult with the Indemnifying Party as to the procedure to be followed in defending, settling, or compromising the Claim; (c) shall not consent to any settlement or compromise of a Third Party Claim without the written consent of the Indemnifying Party; (d) shall permit the Indemnifying Party to assume the defense of a Third Party Claim (including, except as provided below, the compromise or settlement thereof) at the Indemnifying Party’s own cost and expense, provided, however, that the Indemnified Person shall have the right to approve the Indemnifying Party's choice of legal counsel.

  • HOLD HARMLESS AND INDEMNIFICATION To the fullest extent permitted by law, Contractor shall defend (with counsel of District’s choosing), indemnify and hold the District, its officials, officers, employees, volunteers and agents free and harmless from any and all claims, demands, causes of action, costs, expenses, liability, loss, damage or injury of any kind, in law or equity, to property or persons, including wrongful death, in any manner arising out of, pertaining to, or incident to any alleged acts, errors or omissions, or willful misconduct of Contractor, its officials, officers, employees, subcontractors, Contractors or agents in connection with the performance of the Contractor's Services, the Project or this Agreement, including without limitation the payment of all consequential damages, expert witness fees and attorneys fees and other related costs and expenses. Contractor shall reimburse District and its officials, officers, employees, agents, and/or volunteers, for any and all legal expenses and costs incurred by each of them in connection therewith or in enforcing the indemnity herein provided. Contractor's obligation to indemnify shall not be restricted to insurance proceeds, if any, received by the District, its directors, officials officers, employees, agents, or volunteers. Notwithstanding the foregoing, to the extent Contractor's Services are subject to Civil Code Section 2782.8, the above indemnity shall be limited, to the extent required by Civil Code Section 2782.8, to claims that arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor. Contractor agrees to waive all rights of subrogation against the District. a) THE PARTIES UNDERSTAND AND AGREE THAT ARTICLE VIII, PARAGRAPH 1 OF THIS AGREEMENT SHALL BE THE SOLE INDEMNITY, AS DEFINED BY CALIFORNIA CIVIL CODE § 2772, GOVERNING THIS AGREEMENT. ANY OTHER INDEMNITY THAT MAY BE ATTACHED TO THIS AGREEMENT AS AN EXHIBIT SHALL BE VOID AND UNENFORCEABLE BETWEEN THE PARTIES. b) ANY ATTEMPT TO LIMIT THE CONTRACTOR’S LIABILITY TO THE DISTRICT IN AN ATTACHED EXHIBIT SHALL BE VOID AND UNENFORCEABLE BETWEEN THE DISTRICT AND THE CONTRACTOR.

  • Unlawful Indemnification To indemnify the Indemnitee if a final decision by a court having jurisdiction in the matter shall determine that such indemnification is not lawful. In this respect, the Company and the Indemnitee have been advised that the Securities and Exchange Commission takes the position that indemnification for liabilities arising under the federal securities laws is against public policy and is, therefore, unenforceable and that claims for indemnification should be submitted to appropriate courts for adjudication.

  • Indemnification/Hold Harmless As a separate and independent covenant from CONTRACTOR’s obligations under Section 22 hereof, CONTRACTOR shall indemnify, protect, defend with counsel acceptable to the CITY, and hold CITY and CITY’s officers, employees, agents, and volunteers harmless and free from any and all claims, liabilities, or expenses, including attorney’s fees, arising out of or relating to any negligent act, negligent omission, or wrongful conduct, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), related in any way to CONTRACTOR’s performance of its services pursuant to this Agreement. In the event CITY and/or any of CITY’s officers, employees, agents, or volunteers are named in any lawsuit, or should any claim be made against it or any of them by lawsuit or otherwise arising out of or relating to such negligent act, negligent omission, wrongful conduct, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), CONTRACTOR shall indemnify them for any judgment rendered against them for such negligent act, negligent omission, wrongful act, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), any sums paid out in settlement or otherwise, and all costs incurred by them in their defense, including but not limited to attorney’s fees. XXXXXXXXXX also understands and agrees that it is being employed to perform the services provided for by this Agreement because of CONTRACTOR’s professed expertise and experience in performing such services. In addition, CONTRACTOR understands and agrees that while CITY or CITY’s officers, employees, agents, or volunteers may elect to do so, they have no duty to review, inspect, monitor, or supervise the work performed by CONTRACTOR pursuant to this Agreement except as otherwise expressly provided for by this Agreement. As a consequence, CONTRACTOR waives any right of contribution against CITY or any of CITY’s officers, employees, agents, or volunteers arising out of such failure to inspect, review, monitor, or supervise the work performed by CONTRACTOR pursuant to this Agreement. CONTRACTOR’s obligations under this Section of the Agreement shall survive the termination of the Agreement.

  • Agreement to Indemnify (a) In the event Indemnitee was, is or becomes a party to or witness or other participant in, or is threatened to be made a party to or witness or other participant in, a Proceeding by reason of (or arising in part out of) an Indemnifiable Event, the Company shall indemnify Indemnitee to the fullest extent permitted by law, as soon as practicable but in any event no later than thirty (30) days after written demand is presented to the Company, against any and all Expenses, judgments, fines, penalties and amounts paid in settlement (including all interest, assessments and other charges paid or payable in connection with or in respect of such Expenses, judgments, fines, penalties or amounts paid in settlement) of such Proceeding and any federal, state, local or foreign taxes imposed on the Indemnitee as a result of the actual or deemed receipt of any payments under this Agreement, including the creation of the Trust pursuant to Section 4 hereof. Notwithstanding anything in this Agreement to the contrary and except as provided in Section 5, Indemnitee shall not be entitled to indemnification pursuant to this Agreement in connection with any Proceeding initiated by Indemnitee against the Company or any director or officer of the Company unless the Company has joined in or consented to the initiation of such Proceeding. If so requested by Indemnitee, the Company shall advance, within ten (10) business days of such request, any and all Expenses to Indemnitee (an "Expense Advance"); provided, however, that such Expenses shall be advanced only upon delivery to the Company of an undertaking by or on behalf of the Indemnitee to repay such amount if it is ultimately determined that Indemnitee is not entitled to be indemnified by the Company; provided further, that the Company shall make such advances only to the extent permitted by law. (b) Notwithstanding the foregoing, (i) the obligations of the Company under Section 2(a) shall be subject to the condition that the Reviewing Party shall not have determined (in a written opinion, in any case in which the special, independent counsel referred to in Section 3 hereof is involved) that Indemnitee would not be permitted to be indemnified under applicable law, and (ii) the obligation of the Company to make an Expense Advance pursuant to Section 2(a) shall be subject to the condition that, if, when and to the extent that the Reviewing Party determines that Indemnitee would not be permitted to be so indemnified under applicable law, the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all such amounts theretofore paid; provided, however, that if Indemnitee has commenced legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee should be indemnified under applicable law, any determination made by the Reviewing Party that Indemnitee would not be permitted to be indemnified under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expense Advance until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or have lapsed). Indemnitee's obligation to reimburse the Company for Expense Advances shall be unsecured and no interest shall be charged thereon, to the extent permitted by law. If there has not been a Change in Control, the Reviewing Party shall be selected by the Board of Directors, and if there has been such a Change in Control, other than a Change in Control which has been approved by a majority of the Company's Board of Directors who were directors immediately prior to such Change in Control, the Reviewing Party shall be the special, independent counsel referred to in Section 3 hereof. If there has been no determination by the Reviewing Party or if the Reviewing Party determines that Indemnitee substantively would not be permitted to be indemnified in whole or in part under applicable law, Indemnitee shall have the right to commence litigation in any court in the States of California or Delaware having subject matter jurisdiction thereof and in which venue is proper seeking an initial determination by the court or challenging any such determination by the Reviewing Party or any aspect thereof, and the Company hereby consents to service of process and to appear in any such proceeding. Any determination by the Reviewing Party otherwise shall be conclusive and binding on the Company and Indemnitee.

  • Indemnify and Hold Harmless The Trust shall be the policy holder of any insurance plan or health care coverage plan offered by and through the Trust. As the policy holder, the Trust shall indemnify and hold harmless from liability the Employer from any claims by beneficiaries, health care providers, vendors, insurance carriers or home care workers covered under this Agreement.

  • ADDITIONAL INDEMNIFICATION, HOLD HARMLESS AND EXONERATION RIGHTS Notwithstanding any limitation in Sections 3, 4, or 5, except for Section 27, the Company shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee if Indemnitee is a party to or threatened to be made a party to any Proceeding (including a Proceeding by or in the right of the Company to procure a judgment in its favor) against all Expenses, judgments, fines, penalties and amounts paid in settlement (including all interest, assessments and other charges paid or payable in connection with or in respect of such Expenses, judgments, fines, penalties and amounts paid in settlement) actually and reasonably incurred by Indemnitee in connection with the Proceeding. No indemnification, hold harmless or exoneration rights shall be available under this Section 7 on account of Indemnitee’s conduct which constitutes a breach of Indemnitee’s duty of loyalty to the Company or its stockholders or is an act or omission not in good faith or which involves intentional misconduct or a knowing violation of the law.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!