Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Operations and Maintenance Seller shall not during the months of June through September inclusive schedule any non-emergency maintenance that reduces the energy generating capability of the Facility by more than ten percent (10%), unless (i) such outage is required to avoid damage to the Facility, (ii) such maintenance is necessary to maintain equipment warranties and cannot be scheduled outside the months of June through September, (iii) such outage is required in accordance with prudent electrical practices, or (iv) the Parties agree otherwise in writing.
Contractual and Operational Compliance Audits (a) ICANN may from time to time (not to exceed twice per calendar year) conduct, or engage a third party to conduct, contractual compliance audits to assess compliance by Registry Operator with its representations and warranties contained in Article 1 of this Agreement and its covenants contained in Article 2 of this Agreement. Such audits shall be tailored to achieve the purpose of assessing compliance, and ICANN will (a) give reasonable advance notice of any such audit, which notice shall specify in reasonable detail the categories of documents, data and other information requested by ICANN, and (b) use commercially reasonable efforts to conduct such audit during regular business hours and in such a manner as to not unreasonably disrupt the operations of Registry Operator. As part of such audit and upon request by ICANN, Registry Operator shall timely provide all responsive documents, data and any other information reasonably necessary to demonstrate Registry Operator’s compliance with this Agreement. Upon no less than ten (10) calendar days notice (unless otherwise agreed to by Registry Operator), ICANN may, as part of any contractual compliance audit, conduct site visits during regular business hours to assess compliance by Registry Operator with its representations and warranties contained in Article 1 of this Agreement and its covenants contained in Article 2 of this Agreement. ICANN will treat any information obtained in connection with such audits that is appropriately marked as confidential (as required by Section 7.15) as Confidential Information of Registry Operator in accordance with Section 7.15.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
GENERAL WORKING CONDITIONS Section 18-1. Employment begins and ends at each project site. Section 18-2. The selection of craft foremen and/or general foremen and the number of foremen required shall be entirely the responsibility of the Employer, it being understood that in the selection of such foremen and/or general foremen the Employer will give primary consideration to the qualified individuals available in the local area. After giving such consideration, the Employer may select such individuals from other areas. All foremen shall take orders from the designated Employer representatives. Craft foremen shall be designated working foremen at the request of the Employer. Section 18-3. There shall be no limit on production by employees nor restrictions on the full use of tools or equipment. Employees using tools shall perform any of the work of the trade and shall work under the direction of the craft foremen. There shall be no restrictions on efficient use of manpower other than as may be required by safety regulations. Section 18-4. Employees shall be at their place of work at the starting time and shall remain at their place of work performing their assigned functions under the supervision of the Employer until quitting time. The parties reaffirm their policy of a fair day’s work for a fair day’s wage. Section 18-5. All equipment assigned to a project shall be under the control of the Employer. The Employer shall have the right to determine how many pieces of equipment an individual employee shall operate. In an emergency, foremen shall operate any equipment assigned by the Employer, and there shall be no restriction on foremen in the use of the tools of his or her craft in such emergency. The foremen shall be from the craft normally operating the equipment. In accordance with currently recognized craft jurisdiction, the Employer shall determine the assignment of employees to start, stop, and maintain small portable construction equipment. Such work may be assigned to craft employees within a reasonable distance of their primary duties or an employee may be assigned full time to start, stop and maintain the Employer’s small, portable equipment on the job site. There shall be no over xxxxxxx of this type of equipment. The number of employees assigned to rigging and scaffolding operations shall be at the sole discretion of the Employer. The ratio of journeyperson to welders shall be determined solely by the Employer. Section 18-6. The Employer may utilize the most efficient methods or techniques of construction, tools or other labor saving devices to accomplish the work. Practices not a part of the terms and conditions of this Agreement, stand by crews and feather bedding practices will not be recognized. Section 18-7. It is recognized that specialized or unusual equipment may be installed and/ or serviced by individuals who have special training, skill, or qualifications and are not covered by this Agreement. Testing, inspection, or service performed on plant equipment under warranty may be performed by the vendor’s personnel. Section 18-8. Neither the Union nor its local unions shall coerce or in any way interfere with the Owner’s personnel, operation or facilities at the plant site. The Owner’s right to contract directly with other companies for work at the plant site shall not be limited, and the Union shall cooperate and not interfere with the Employer’s operations. Section 18-9. It is agreed that overtime is undesirable and not in the best interest of the industry or the employees; therefore, except in unusual circumstances, overtime will not be worked. Where unusual circumstances do exist, however, the Employer will have the right to assign specific employees and/or crews to perform such overtime work as is necessary to accomplish the job. Section 18-10. There will be no rest periods, organized coffee breaks or other non-working time established during working hours. Section 18-11. Individual seniority shall not be recognized or applied to employees working on projects under this Agreement. Section 18-12. The Employer shall establish such reasonable project rules as the Employer deems appropriate. These rules will be reviewed at the pre-job conference and posted at the project site by the Employer, and may be amended thereafter as necessary.
Operation and Maintenance 17.1 O&M obligations of the Concessionaire 17.1.1 During the Operation Period, the Concessionaire shall operate and maintain the Bus Terminal in accordance with this Agreement either by itself, or through the O&M Contractor and if required, modify, repair or otherwise make improvements to the Bus Terminal to comply with the provisions of this Agreement, Applicable Laws and Applicable Permits, and conform to Specifications and Standards and Good Industry Practice. The obligations of the Concessionaire hereunder shall include: (a) permitting safe, smooth and uninterrupted flow of traffic on the Bus Terminal during normal operating conditions. Buses of other state road transport corporations shall be parked inside the Bus Terminal for which no charges shall be payable to the Concessionaire and if any charges are applicable for such parking then it shall be realized by Authority only; (b) minimising incidents affecting the safety and use of the Bus Terminal by providing a rapid and effective response and maintaining liaison with emergency services of the State; (c) carrying out periodic preventive maintenance of the Bus Terminal; (d) undertaking routine maintenance including prompt repairs of ticket counters, Workshops, Authority's Office and other infrastructure as mentioned in the Operation and Maintenance Schedule; (e) undertaking major maintenance such as per the Maintenance Schedule of the major infrastructure in the Bus Terminal; (f) preventing, with the assistance of the concerned law enforcement agencies, any encroachments on the Bus Terminal; (g) protection of the environment and provision of equipment and materials therefor; (h) operation and maintenance of all communication, control and administrative systems necessary for the efficient operation of the Bus Terminal; (i) maintaining a public relations unit to interface with and attend to suggestions from the Users, passengers, government agencies, media and other agencies; (j) complying with Safety Requirements in accordance with Article 18; (k) operation and maintenance of all Project Assets diligently and efficiently and in accordance with Good Industry Practice; (l) maintaining punctuality and reliability in operating the Bus Terminal; and (m) maintaining a high standard of cleanliness and hygiene in the Bus Terminal. 17.1.2 The Concessionaire shall remove promptly from the Bus Terminal all surplus construction machinery and materials, waste materials (including hazardous materials and waste water), rubbish and other debris (including, without limitation, accident debris) and keep the Bus Terminal in a clean, tidy and orderly condition,
Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.
Maintenance and Operation Member-Generator agrees to maintain their system and facilities in accordance with applicable manufacturer's recommended maintenance schedule and standard prudent engineering practices. Member-Generator covenants and agrees to operate their system, facilities and equipment so as to minimize the likelihood for a malfunction or other disturbance, damaging or otherwise affecting or impairing Cooperative’s electrical system. Member-Generator shall comply with all applicable laws, regulations, zoning, building codes, safety rules and other environmental regulations or restrictions applicable to the design, installation, operation and maintenance of the Member-Generator's System.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Management and Operation of Business Section 7.1 Management 47 Section 7.2 Certificate of Limited Partnership 48 Section 7.3 Restrictions on Managing General Partner’s Authority 49 Section 7.4 Reimbursement of the Managing General Partner 49 Section 7.5 Outside Activities 50 Section 7.6 Loans from the Managing General Partner; Loans or Contributions from the Partnership; Contracts with Affiliates; Certain Restrictions on the Managing General Partner 51 Section 7.7 Indemnification 53 Section 7.8 Liability of Indemnitees 54 Section 7.9 Resolution of Conflicts of Interest 55 Section 7.10 Other Matters Concerning the Managing General Partner 57 Section 7.11 Purchase or Sale of Partnership Securities 57 Section 7.12 Registration Rights of the Managing General Partner and its Affiliates 57 Section 7.13 Reliance by Third Parties 59