OVERSIGHT OF LARGE STATE CONTRACTS DOES NOT APPLY Sample Clauses

OVERSIGHT OF LARGE STATE CONTRACTS DOES NOT APPLY. The following Article is applicable to those contracts with an aggregate value of Five Million Dollars ($5,000,000) or more. If an officer, employee or appointing authority of the Consulting Engineer takes or threatens to take any personnel action against any employee of the Consulting Engineer in retaliation for such employee's disclosure of information to any employee if the State or quasi-public agency (if applicable) or the Auditors of Public Accounts or the Attorney General under the provisions of Connecticut General Statutes Section 4-61dd(a), the Consulting Engineer shall be liable for a civil penalty of not more than Five Thousand Dollars for each offense, up to a maximum of twenty percent of the value of the contract. Each violation shall be a separate and distinct offense and in the case of a continuing violation each calendar day's continuance of the violation shall be deemed to be a separate and distinct offense. The executive head of the Department may request the Attorney General to bring a civil action in the superior court for the judicial district of Hartford to seek imposition and recovery of such civil penalty. The Consulting Engineer shall post a notice of the provisions of this section in a conspicuous place which is readily available for viewing by the employees of the Consulting Engineer.
Sample 1
AutoNDA by SimpleDocs

Related to OVERSIGHT OF LARGE STATE CONTRACTS DOES NOT APPLY

  • Choice of Law clauses with TIPS Members If the vendor is awarded a contract with TIPS under this solicitation, the vendor agrees to make any Choice of Law clauses in any contract or agreement entered into between the awarded vendor and with a TIPS member entity to read as follows: "Choice of law shall be the laws of the state where the customer resides" or words to that effect.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • CFR PART 200 Contract Provisions Explanation Required Federal contract provisions of Federal Regulations for Contracts for contracts with ESC Region 8 and TIPS Members: The following provisions are required to be in place and agreed if the procurement is funded in any part with federal funds. The ESC Region 8 and TIPS Members are the subgrantee or Subrecipient by definition. Most of the provisions are located in 2 CFR PART 200 - Appendix II to Part 200—Contract Provisions for Non-Federal Entity Contracts Under Federal Awards at 2 CFR PART 200. Others are included within 2 CFR part 200 et al. In addition to other provisions required by the Federal agency or non-Federal entity, all contracts made by the non- Federal entity under the Federal award must contain provisions covering the following, as applicable.

  • CFR PART 200 AND FEDERAL CONTRACT PROVISIONS EXPLANATION TIPS and TIPS Members will sometimes seek to make purchases with federal funds. In accordance with 2 C.F.R. Part 200 of the Uniform Administrative Requirements, Cost Principles, and Audit Requirements for Federal Awards (sometimes referred to as “XXXXX”),Vendor's response to the following questions labeled "2 CFR Part 200 or Federal Provision" will indicate Vendor's willingness and ability to comply with certain requirements which may be applicable to TIPS purchases paid for with federal funds, if accepted by Vendor. Your responses to the following questions labeled "2 CFR Part 200 or Federal Provision" will dictate whether TIPS can list this awarded contract as viable to be considered for a federal fund purchase. Failure to certify all requirements labeled "2 CFR Part 200 or Federal Provision" will mean that your contract is listed as not viable for the receipt of federal funds. However, it will not prevent award. If you do enter into a TIPS Sale when you are accepting federal funds, the contract between you and the TIPS Member will likely require these same certifications.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Compliance with Contracts and Credit and Collection Policy Originator will timely and fully (i) perform and comply with all provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and (ii) comply in all respects with the Credit and Collection Policy in regard to each Receivable and the related Contract.

  • Direction to Account Debtors; Contracting Parties; etc Upon the occurrence and during the continuance of an Event of Default, if the Collateral Agent so directs any Assignor, such Assignor agrees (x) to cause all payments on account of the Receivables and Contracts to be made directly to one or more Cash Collateral Accounts (as the Collateral Agent shall so direct), (y) that the Collateral Agent may, at its option, directly notify the obligors with respect to any Receivables and/or under any Contracts to make payments with respect thereto as provided in the preceding clause (x), and (z) that the Collateral Agent may enforce collection of any such Receivables and Contracts and may adjust, settle or compromise the amount of payment thereof, in the same manner and to the same extent as such Assignor. Without notice to or assent by any Assignor, the Collateral Agent may, upon the occurrence and during the continuance of an Event of Default, apply any or all amounts then in, or thereafter deposited in, the Cash Collateral Accounts which application shall be effected in the manner provided in Section 7.4 of this Agreement. The reasonable costs and expenses (including reasonable attorneys' fees) of collection, whether incurred by an Assignor or the Collateral Agent, shall be borne by the relevant Assignor. The Collateral Agent shall deliver a copy of each notice referred to in the preceding clause (y) to the relevant Assignor, provided, that the failure by the Collateral Agent to so notify such Assignor shall not affect the effectiveness of such notice or the other rights of the Collateral Agent created by this Section 3.3.

  • Proposed Policies and Procedures Regarding New Online Content and Functionality By October 31, 2017, the School will submit to OCR for its review and approval proposed policies and procedures (“the Plan for New Content”) to ensure that all new, newly-added, or modified online content and functionality will be accessible to people with disabilities as measured by conformance to the Benchmarks for Measuring Accessibility set forth above, except where doing so would impose a fundamental alteration or undue burden. a) When fundamental alteration or undue burden defenses apply, the Plan for New Content will require the School to provide equally effective alternative access. The Plan for New Content will require the School, in providing equally effective alternate access, to take any actions that do not result in a fundamental alteration or undue financial and administrative burdens, but nevertheless ensure that, to the maximum extent possible, individuals with disabilities receive the same benefits or services as their nondisabled peers. To provide equally effective alternate access, alternates are not required to produce the identical result or level of achievement for persons with and without disabilities, but must afford persons with disabilities equal opportunity to obtain the same result, to gain the same benefit, or to reach the same level of achievement, in the most integrated setting appropriate to the person’s needs. b) The Plan for New Content must include sufficient quality assurance procedures, backed by adequate personnel and financial resources, for full implementation. This provision also applies to the School’s online content and functionality developed by, maintained by, or offered through a third-party vendor or by using open sources. c) Within thirty (30) days of receiving OCR’s approval of the Plan for New Content, the School will officially adopt, and fully implement the amended policies and procedures.

  • Maintenance of PMI Policy and/or LPMI Policy; Claims The Servicer shall comply with all provisions of applicable state and federal law relating to the cancellation of, or collection of premiums with respect to, PMI Policies, including, but not limited to, the provisions of the Homeowners Protection Act of 1998, and all regulations promulgated thereunder, as amended from time to time. With respect to each Mortgage Loan (other than LPMI Loans) with a loan to value ratio at origination in excess of 80%, the Servicer shall maintain or cause the Mortgagor to maintain (to the extent that the Mortgage Loan requires the Mortgagor to maintain such insurance) in full force and effect a PMI Policy, and shall pay or shall cause the Mortgagor to pay the premium thereon on a timely basis, until the LTV of such Mortgage Loan is reduced to 80%. In the event that such PMI Policy shall be terminated, the Servicer shall obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated PMI Policy, at substantially the same fee level. The Servicer shall not take any action which would result in noncoverage under any applicable PMI Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreements entered into or to be entered into with respect to a Mortgage Loan, the Servicer shall promptly notify the insurer under the related PMI Policy, if any, of such assumption or substitution of liability in accordance with the terms of such PMI Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such PMI Policy. If such PMI Policy is terminated as a result of such assumption or substitution of liability, the Servicer shall obtain a replacement PMI Policy as provided above. The Servicer shall take all such actions as are necessary to service, maintain and administer the LPMI Loans in accordance with the LPMI Policy and to perform and enforce the rights of the insured under such LPMI Policy. Except as expressly set forth herein, the Servicer shall have full authority on behalf of the Trust Fund to do anything it reasonably deems appropriate or desirable in connection with the servicing, maintenance and administration of the LPMI Policy. The Servicer shall not modify or assume a Mortgage Loan covered by the LPMI Policy or take any other action with respect to such Mortgage Loan which would result in non-coverage under the LPMI Policy of any loss which, but for the actions of the Servicer, would have been covered thereunder. If the LPMI Insurer fails to pay a claim under the LPMI Policy as a result of breach by the Servicer of its obligations hereunder or under the LPMI Policy, the Servicer shall be required to deposit in the Custodial Account on or prior to the next succeeding Remittance Date an amount equal to such unpaid claim from its own funds without any right to reimbursement from the Trust Fund. The Servicer shall cooperate with the LPMI Insurer and the Master Servicer and shall use its best efforts to furnish all reasonable aid, evidence and information in the possession of the Servicer to which the Servicer has access with respect to any LPMI Loan; provided, however, notwithstanding anything to the contrary contained in any LPMI Policy, the Servicer shall not be required to submit any reports to the LPMI Insurer until a reporting date that is at least 15 days after the Servicer has received sufficient loan level information from the Seller, the Master Servicer or the LPMI Insurer to appropriately code its servicing system in accordance with the LPMI Insurer’s requirements. In connection with its activities as servicer, the Servicer agrees to prepare and present, on behalf of itself and the Trustee, claims to the insurer under any PMI Policy or LPMI Policy in a timely fashion in accordance with the terms of such PMI Policy or LPMI Policy and, in this regard, to take such action as shall be necessary to permit recovery under any PMI Policy or LPMI Policy respecting a defaulted Mortgage Loan. Any amounts collected by the Servicer under any PMI Policy or LPMI Policy shall be deposited in the Custodial Account, subject to withdrawal pursuant to Section 3.04.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!