Owner and Construction Manager agree and acknowledge Sample Clauses

Owner and Construction Manager agree and acknowledge that Owner is entering into this Agreement in reliance on Construction Manager's special and unique abilities with respect to construction management and the obligations of this Agreement. Construction Manager accepts the relationship of trust and confidence established between it and Owner by this Agreement. Construction Manager shall use its best efforts, skill, judgment, and abilities to perform the services hereunder and to further the interests of Owner in accordance with Owner’s requirements and procedures, in accordance with the highest standards of Construction Manager’s profession or business and in compliance with all applicable national, federal, state, municipal, laws, regulations, codes, ordinances, orders, local utility companies and with those of any other body having jurisdiction. Construction Manager shall have no obligations, commitments, or impediments of any kind that will limit or prevent performance of the services required hereunder.
Sample 1
AutoNDA by SimpleDocs

Related to Owner and Construction Manager agree and acknowledge

  • Agreements and Acknowledgements Regarding Hedging Counterparty understands, acknowledges and agrees that: (A) at any time on and prior to the Expiration Date, Dealer and its affiliates may buy or sell Shares or other securities or buy or sell options or futures contracts or enter into swaps or other derivative securities in order to adjust its hedge position with respect to the Transaction; (B) Dealer and its affiliates also may be active in the market for Shares other than in connection with hedging activities in relation to the Transaction; (C) Dealer shall make its own determination as to whether, when or in what manner any hedging or market activities in securities of Issuer shall be conducted and shall do so in a manner that it deems appropriate to hedge its price and market risk with respect to the Relevant Prices; and (D) any market activities of Dealer and its affiliates with respect to Shares may affect the market price and volatility of Shares, as well as the Relevant Prices, each in a manner that may be adverse to Counterparty.

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Records and Documentation The Sub-Recipient agrees to make available to AAAPP staff and/or any party designated by the AAAPP any and all contract related records and documentation. The Sub-Recipient shall ensure the collection and maintenance of all program related information and documentation on any such system designated by the AAAPP. Maintenance includes valid exports and backups of all data and systems according to AAAPP standards.

  • Agreements and Acknowledgments Regarding Shares (i) Counterparty agrees and acknowledges that, in respect of any Shares delivered to Dealer hereunder, such Shares shall be newly issued (unless mutually agreed otherwise by the parties) and, upon such delivery, duly and validly authorized, issued and outstanding, fully paid and nonassessable, free of any lien, charge, claim or other encumbrance and not subject to any preemptive or similar rights and shall, upon such issuance, be accepted for listing or quotation on the Exchange. (ii) Counterparty agrees and acknowledges that Dealer (or an affiliate of Dealer) will hedge its exposure to the Transaction by selling Shares borrowed from third party securities lenders or other Shares pursuant to a registration statement, and that, pursuant to the terms of the Interpretive Letter, the Shares (up to the Initial Number of Shares) delivered, pledged or loaned by Counterparty to Dealer (or an affiliate of Dealer) in connection with the Transaction may be used by Dealer (or an affiliate of Dealer) to return to securities lenders without further registration or other restrictions under the Securities Act of 1933, as amended (the “Securities Act”), in the hands of those securities lenders, irrespective of whether such securities loan is effected by Dealer or an affiliate of Dealer. Accordingly, subject to Paragraph 7(h) below, Counterparty agrees that the Shares that it delivers, pledges or loans to Dealer (or an affiliate of Dealer) on or prior to the final Settlement Date will not bear a restrictive legend and that such Shares will be deposited in, and the delivery thereof shall be effected through the facilities of, the Clearance System. (iii) Counterparty agrees and acknowledges that it has reserved and will keep available at all times, free from preemptive or similar rights and free from any lien, charge, claim or other encumbrance, authorized but unissued Shares at least equal to the Share Cap, solely for the purpose of settlement under the Transaction. (iv) Unless the provisions set forth below under “Private Placement Procedures” are applicable, Dealer agrees to use any Shares delivered by Counterparty hereunder on any Settlement Date to return to securities lenders to close out open securities loans created by Dealer or an affiliate of Dealer in the course of Dealer’s or such affiliate’s hedging activities related to Dealer’s exposure under the Transaction. (v) In connection with bids and purchases of Shares in connection with any Cash Settlement or Net Share Settlement of the Transaction, Dealer shall use its good faith efforts to conduct its activities, or cause its affiliates to conduct their activities, in a manner consistent with the requirements of the safe harbor provided by Rule 10b-18, as if such provisions were applicable to such purchases and any analogous purchases under any Additional Transaction, taking into account any applicable SEC no action letters, as appropriate.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • Lenders’ Representations, Warranties and Acknowledgment (a) Each Lender represents and warrants that it has made its own independent investigation of the financial condition and affairs of Borrower and its respective Subsidiaries in connection with Credit Extensions hereunder and that it has made and shall continue to make its own appraisal of the creditworthiness of Borrower and its Subsidiaries. No Agent shall have any duty or responsibility, either initially or on a continuing basis, to make any such investigation or any such appraisal on behalf of Lenders or to provide any Lender with any credit or other information with respect thereto, whether coming into its possession before the making of the Loans or at any time or times thereafter, and no Agent shall have any responsibility with respect to the accuracy of or the completeness of any information provided to Lenders. (b) Each Lender, by delivering its signature page to this Agreement, or an Assignment Agreement or a Joinder Agreement and funding its Tranche A Term Loans, Tranche B Term Loans, New Term Loans and/or Revolving Loans shall be deemed to have acknowledged receipt of, and consented to and approved, each Credit Document and each other document required to be approved by any Agent, Requisite Lenders or Lenders, as applicable on the Original Closing Date, on the First Restatement Date, on the Second Restatement Date, on the Second Amendment and Restatement Joinder Date, on the Third Restatement Date or as of the date of funding of such New Term Loans and/or Revolving Loans.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • Additional Covenants Agreements and Acknowledgements a. [Intentionally Omitted].

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!