Owner Consultants Sample Clauses

Owner Consultants. The Architect/Engineer shall cooperate at all times with the Owner and shall cooperate and coordinate with any separate consultant or agent hired by the Owner. The Architect/Engineer shall incorporate the work product of any Owner consultant in a manner which is appropriate to facilitate the design and construction of the Project within the Project Construction Budget and Project Schedule.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Owner Consultants. The T&B Firm shall cooperate at all times with the Owner and shall cooperate and coordinate with any separate consultant or agent hired by the Owner. The T&B Firm shall incorporate the work product of any Owner consultant in a manner which is appropriate to facilitate the construction of the Project within the Project Construction Budget and Project Schedule.
Sample 1Sample 2Sample 3See All (4)
Owner Consultants. Except to the extent of Design Consultants retained by the Architect, other consultants required or desired by the Owner in connection with the Project shall be retained and paid for by the Owner.
Sample 1Sample 2
Owner Consultants. The GEOTECH Firm shall cooperate at all times with the Owner and shall cooperate and coordinate with any separate consultant or agent hired by the Owner. The GEOTECH Firm shall incorporate the work product of any Owner consultant in a manner which is appropriate to facilitate the construction of the Project within the Project Construction Budget and Project Schedule.
Sample 1Sample 2
Owner Consultants. The Owner shall retain all contractors and consultants necessary to carry out the Project except for those consultants retained by the Program Manager as set forth in this Agreement. The Owner shall provide the Program Manager with a copy of all executed agreements between the Owner and its consultants and contractors, and any modifications to those agreements. The Owner shall require that its consultants maintain professional liability insurance and other liability insurance as appropriate to the services provided meeting the requirements of the Lease and Loan Documents, and require that its contractors maintain commercial general liability insurance and other liability insurance as appropriate to the services or work provided meeting the requirements of the Lease and Loan Documents. The Owner shall require all contractors to name the Program Manager and its consultants as Additional Insureds on all insurance policies where available.
Sample 1
Owner Consultants. The Owner shall retain all contractors and consultants necessary to carry out the Project except for those consultants retained by the Program Manager as set forth in this Agreement. The Owner shall provide the Program Manager with copies of (i) all executed agreements between the Owner and its consultants and contractors, and any modifications to those agreements, pertaining to the Project, (ii) the Lease, and (iii) the documentation for the Project Loan (the Lease and the Project Loan documentation is collectively the “Master Documentation”). The Program Manager shall assist Owner to require (i) its consultants to maintain professional liability insurance and other liability insurance as required by the Master Documentation, and as appropriate to the services provided, and (ii) its contractors to maintain commercial general liability insurance and other liability insurance as required by the Master Documentation and as appropriate to the services or work provided. The Owner shall require all contractors to name the Program Manager and its consultants as Additional Insureds on all insurance policies where available.
Sample 1

Related to Owner Consultants

  • Sub-Consultants All sub-consultants shall comply with each and every insurance provision of this Section 3.

  • Subconsultants Whichever of the following is marked applies to this Approved Service Order: The Consultant can not use any subconsultants. The Consultant can use the following subconsultants to assist in providing the required services and deliverables: 2. 3.

  • Other Consultants The City reserves the right to employ other consultants in connection with the Work.

  • Individual Consultants Services for assignments that meet the requirements set forth in the first sentence of paragraph 5.1 of the Consultant Guidelines may be procured under contracts awarded to individual consultants in accordance with the provisions of paragraphs 5.2 through 5.3 of the Consultant Guidelines. Under the circumstances described in paragraph 5.4 of the Consultant Guidelines, such contracts may be awarded to individual consultants on a sole-source basis.

  • Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.

  • Consultants Any and all consultant(s), sub-consultant(s), subcontractor(s), or agent(s) to the Architect.

  • Employees and Consultants Pubco does not have any employees or consultants, except as disclosed in the Pubco SEC Documents.

  • Contractor’s Employees and Subcontractors (a) Contractor shall only disclose PII to Contractor’s employees and subcontractors who need to know the PII in order to provide the Services and the disclosure of PII shall be limited to the extent necessary to provide such Services. Contractor shall ensure that all such employees and subcontractors comply with the terms of this DPA. (b) Contractor must ensure that each subcontractor performing functions pursuant to the Service Agreement where the subcontractor will receive or have access to PII is contractually bound by a written agreement that includes confidentiality and data security obligations equivalent to, consistent with, and no less protective than, those found in this DPA. (c) Contractor shall examine the data security and privacy measures of its subcontractors prior to utilizing the subcontractor. If at any point a subcontractor fails to materially comply with the requirements of this DPA, Contractor shall: notify the EA and remove such subcontractor’s access to PII; and, as applicable, retrieve all PII received or stored by such subcontractor and/or ensure that PII has been securely deleted and destroyed in accordance with this DPA. In the event there is an incident in which the subcontractor compromises PII, Contractor shall follow the Data Breach reporting requirements set forth herein. (d) Contractor shall take full responsibility for the acts and omissions of its employees and subcontractors. (e) Contractor must not disclose PII to any other party unless such disclosure is required by statute, court order or subpoena, and the Contractor makes a reasonable effort to notify the EA of the court order or subpoena in advance of compliance but in any case, provides notice to the EA no later than the time the PII is disclosed, unless such disclosure to the EA is expressly prohibited by the statute, court order or subpoena.

  • Employees and Subcontractors It is understood that, from time to time, it may become necessary for the Contractor to replace an individual working as an employee or subcontractor of the Contractor. All such removals or replacements shall be subject to Owner’s prior approval. Owner reserves the right to approve a replacement, which approval shall not be unreasonably withheld, or terminate the Work, either partially or in its entirety without further obligation to the Contractor thereunder other than to remit payment for the Work rendered up to the termination date. Contractor agrees that Owner may, at any time, with cause, require Contractor to remove an individual from the performance of the Work. An election by Owner of any of its rights under this Section 19 shall not affect the Contractor’s responsibilities, liabilities or warranties under this Agreement.

  • Employees and Contractors The Recipient agrees to disclose Confidential Information to any agents, affiliates, directors, officers, or any other employees, collectively known as the “Employees,” solely on a need-to-know basis and represents that such Employees have signed appropriate non-disclosure agreements or have taken appropriate measures imposing on such Employees a duty to third parties: i.) To hold any third-party proprietary information received by such Employees in the strictest confidence; ii.) Not to disclose such third-party Confidential Information to any other third party; and iii.) Not to use such Confidential Information for the benefit of anyone other than to whom it belongs, without the prior express written authorization of the Owner.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!