Title Objections Seller shall request Escrow Agent to cause to be delivered to Buyer a preliminary title report (the "Preliminary Report") from a title company affiliated with the Escrow Agent (the "Title Company"), showing the status of Seller’s title to the Property, together with complete and legible copies of all documents shown therein as exceptions to title ("Exceptions"). Buyer shall have until the date that is five (5) days after the Title Company delivers the Preliminary Report and Exceptions to Buyer within which to give notice in writing to Seller of any objection to such title or to any liens or encumbrances affecting the Property. Within five (5) days after receipt of such notice from Buyer, Seller shall give Buyer written notice of whether it is willing and able to remove the objected-to Exceptions. Without the need for objection by Buyer, Seller shall, with respect to liens and encumbrances that can be satisfied and released by the payment of money, eliminate such exceptions to title on or before Closing. Within five (5) days after receipt of such notice from Seller (the "Title Contingency Date"), Buyer shall elect whether to: (i) purchase the Property subject to those objected-to Exceptions which Seller is not willing or able to remove; or (ii) terminate this Agreement. If Buyer fails to give Seller notice of Buyer’s election, then such inaction shall be deemed to be Buyer’s election to terminate this Agreement. On or before the Closing Date (defined below), Seller shall remove all Exceptions to which Buyer objects and which Seller agrees, or is deemed to have agreed, Seller is willing and able to remove. All remaining Exceptions set forth in the Preliminary Report and those Exceptions caused by or agreed to by Buyer shall be deemed "Permitted Exceptions."
Survey or Title Objections If Buyer discovers any title or survey matter which is objectionable to Buyer, Buyer may provide Seller with written notice of its objection to same. Any contrary provisions of Article XV concerning what does or does not constitute delivery notwithstanding, Buyer shall provide and Seller must actually receive, any notice of objections on or before the fifth (5th) day prior to the expiration of the Review Period (the “Title Review Period”). If Seller has not actually received a written notice of objection to any such matter set forth in the Survey or Title Commitment prior to the expiration of the Title Review Period, it shall be conclusively assumed that Buyer has approved same. If Buyer disapproves any condition of title, survey or other matters by written objection to Seller on or before the expiration of the Title Review Period, Seller shall elect either to attempt to cure or not cure any such item and shall notify Buyer of its election by written notice within five (5) days after its receipt of notice from Buyer setting forth title or survey objection. If Seller commits in writing to attempt to cure any such item, then Seller shall be given until the Closing Date to cure any such defect. In the event Seller shall fail to cure a defect which Seller has committed in writing to cure prior to Closing, or if a new title defect arises after the date of Buyer’s Title Commitment or Survey, as applicable, but prior to Closing, then Buyer may elect, in Buyer’s sole and absolute discretion: (i) to waive such objection and proceed to Closing, or (ii) to terminate this Contract and receive a return of the Xxxxxxx Money Deposit. The items shown on the Title Commitment which are not objected to by Buyer as set forth above (other than exceptions and title defects arising after the Title Review Period and other than those standard exceptions which are ordinarily and customarily omitted in the state in which the applicable Hotel is located, so long as Seller provides the appropriate owner’s affidavit, gap indemnity or other documentation reasonably required by the Title Company for such omission) are hereinafter referred to as the “Permitted Exceptions.” In no event shall Permitted Exceptions include liens, or documents evidencing liens, securing any indebtedness (including vehicle or FF&E leases or financing arrangements) any mechanics’ or materialmen’s liens or any claims or potential claims therefor covering the Property or any portion thereof (“Seller Liens”), each of which shall be paid in full by Seller and released at Closing, except to the extent caused by Buyer. If a vehicle or FF&E lease or other financing cannot be released at Closing, Seller shall credit Buyer at Closing with the amount necessary to fully pay off such lease or financing over its term.
FINRA No Objections FINRA shall have raised no objection to the fairness and reasonableness of the underwriting terms and arrangements.
No FINRA Objections FINRA shall not have raised any objection with respect to the fairness and reasonableness of the terms and arrangements under this Agreement.
Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.
No Objection FINRA has confirmed that it has not raised any objection with respect to the fairness and reasonableness of the underwriting terms and arrangements relating to the offering of the Securities.
Title Matters Purchaser has received from the Title ------------- Company a preliminary title commitment for a fee policy having an effective date after the date of the Original Agreement, for an ALTA (or such other form reasonably approved by Purchaser) owner's policy of title insurance with respect to the Property, together with complete and legible copies of all instruments and documents referred to as exceptions to title (collectively, the "Title ----- Commitment"). Except as set forth in the Diligence Notice, Purchaser ---------- acknowledges that it does not have any other objections to title exceptions shown on the Title Commitment. Seller acknowledges and agrees that Seller shall attempt to remedy the objections set forth in the Diligence Notice with respect to the Property. Seller shall have the right to adjourn the Closing Date pursuant to Section 3.6 for up to ninety (90) days for such purpose. If Seller ----------- shall be unable to remove any such title defects to which Purchaser has objected in accordance with this Section 3.3, Purchaser may elect (i) to terminate this ----------- Agreement, and this Agreement shall be of no further force and effect, except as otherwise expressly provided herein, or (ii) to consummate the transactions contemplated hereby, notwithstanding such title defect, without any abatement or reduction in the Purchase Price on account thereof. Purchaser shall make any such election by written notice to Seller given on or prior to the earlier of the Closing Date or the fifth Business Day after Seller's notice of its inability to cure such defect, and time shall be of the essence with respect to the giving of such notices by Purchaser. Failure of Purchaser to give such notice shall be deemed an election by Purchaser to proceed in accordance with clause (ii) above, and such exception shall be a Permitted Encumbrance. Notwithstanding the foregoing, Seller shall be obligated to take any and all actions necessary to remove as a title exception (and shall not have the aforesaid option to not cure) any mortgages, deeds of trust, judgments and other liens of a monetary nature, as well as any liens or encumbrances created, permitted or suffered by Seller from and after the date of the Diligence Notice.
Objections FINRA shall not have raised any objection with respect to the fairness or reasonableness of the underwriting, or other arrangements of the transactions contemplated hereby.
Sellers’ Representative By execution of this Agreement, the Sellers hereby irrevocably and unconditionally appoint Nephron Pharmaceuticals Corporation as the Sellers’ Representative of all Sellers, as the attorney-in-fact for and on behalf of each such Seller, and irrevocably agree that the taking by the Sellers’ Representative of any and all actions and the making of any decisions required or permitted to be taken by it or by a Seller under this Agreement or any Transaction Documents to which the Sellers are a party are hereby authorized and approved in all respects, including without limitation the exercise of the power to (i) receive from Buyer and disburse to Sellers any payments constituting any part of the Purchase Price and receive and disburse from and to any Party or any Third Party which may be contemplated to be made under the Transaction Documents, (ii) agree to, negotiate, enter into settlements and compromises of and comply with orders of courts with respect to any indemnification claims or disputes, (iii) resolve any indemnification claims or disputes, and (iv) take all actions necessary in the judgment of the Sellers’ Representative for the accomplishment of the other terms, conditions and limitations of this Agreement and the Transaction Documents. The Sellers’ Representative has authority and power to act on behalf of the Sellers with respect to this Agreement and the other Transaction Documents and the disposition, settlement or other handling of all indemnification claims, rights or obligations arising from and taken pursuant to this Agreement and the other Transaction Documents. The Sellers irrevocably agree to be bound by all and any such actions taken by the Sellers’ Representative in connection with this Agreement and the other Transaction Documents to which the Sellers are a party, and Sellers and Buyer shall only be required to acknowledge or act upon written communication signed by the Sellers’ Representative. Each Seller agrees that he, she or it has not, and will not, threaten or commence or join any legal action, which term includes, without limitation, any demand for arbitration proceedings and any complaint to any foreign, federal, state or local agency, court or other tribunal, to assert any claim against the Sellers’ Representative or its advisors for acting in such capacity with respect to this Agreement or the other Transaction Documents. If any Seller commences or joins any such prohibited legal action against the Sellers’ Representative, such Seller agrees to promptly indemnify Sellers’ Representative and advisers of Sellers’ THIS EXHIBIT HAS BEEN REDACTED AND IS THE SUBJECT OF A CONFIDENTIAL TREATMENT REQUEST. REDACTED MATERIAL IS MARKED WITH [***] AND HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. Representative for all losses, liabilities, reasonable costs or expenses, including without limitation all reasonable fees, disbursements and other charges of attorneys incurred by Sellers’ Representative and/or its advisers in defending such action as well as any monetary judgment obtained against the Sellers’ Representative in such action. The Sellers’ Representative may resign at any time upon 30 days written notice to the Sellers. THIS EXHIBIT HAS BEEN REDACTED AND IS THE SUBJECT OF A CONFIDENTIAL TREATMENT REQUEST. REDACTED MATERIAL IS MARKED WITH [***] AND HAS BEEN FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION.
Owner’s Representative Owner shall from time to time designate one or more persons to serve as Owner’s representative (“Owner’s Representative”) in all dealings with Manager hereunder. Whenever the approval, consent or other action of Owner is called for hereunder, such approval, consent or action shall be binding on Owner if specified in writing and signed by Owner’s Representative. The initial Owner’s Representative shall be Xxxx X. Xxxxxxx, President. Any Owner’s Representative may be changed at the discretion of Owner, at any time, and shall be effective upon Manager’s receipt of written notice identifying the new Owner’s Representative.
