Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice (which shall be prior written notice except in the event of a circumstance which Landlord in good faith believes to be an emergency) and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or, during the last nine (9) months of the Lease Term or during any period that Tenant is in monetary or material non-monetary default beyond the applicable cure period, if any, expressly set forth in this Lease, tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so after the expiration of any applicable notice and cure period expressly set forth in this Lease. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Common Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Common Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least ten (10) days’ prior written notice of any work to be performed on the Leased Premises, as well as notice within one (1) day after the commencement of such work); and (iii) supplying any services to be provided by Landlord. Landlord shall also have the right, upon reasonable advance notice to Tenant, to access the Building’s vertical risers and the interstitial space above Tenant’s acoustical ceiling to connect new utility and communications lines from other floors to the base Building utility lines; all of such work shall be done after hours or on weekends. Any entry into the Leased Premises or the Common Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof. Landlord shall conduct all of Landlord’s activities on the Leased Premises during such period of entry in a manner designed to cause minimal interference to Tenant and Tenant’s use of the Leased Premises.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Right to Refuse Unsafe Work Employees have the right to refuse to perform unsafe work pursuant to the Occupational Health and Safety Regulations of the Workers Compensation Act.
Right to Refuse Overtime All employees shall have the right to refuse to work overtime, except when required to do so in emergency situations, without being subject to disciplinary action for so refusing.
Landlord’s Right to Terminate Landlord shall have the right to terminate this Lease in the event any of the following occurs, which right may be exercised by delivery to Tenant of a written notice of election to terminate within forty-five (45) days after the date of such damage:
A. The Project is damaged by an Insured Peril to such an extent that the estimated cost to restore exceeds ten percent (10%) of the then actual replacement cost thereof, or the Building in which the Premises is located is damaged to such an extent that the estimated cost to restore exceeds twenty-five percent (25%) of the then actual replacement cost thereof;
B. Either the Project or the Building is damaged by an Uninsured Peril to such an extent that the estimated cost to restore exceeds two percent (2%) of the then actual replacement cost of the Building;
C. The Premises are damaged by any peril within twelve (12) months of the last day of the Lease Term to such an extent that the estimated cost to restore equals or exceeds an amount equal to six (6) times the Base Monthly Rent then due; or
D. Either the Project or the Building is damaged by any peril and, because of the Laws then in force, (i) cannot be restored at reasonable cost to substantially the same condition in which it was prior to such damage, or (ii) cannot be used for the same use being made thereof before such damage if restored as required by this Article.
E. As used herein, the following terms shall have the following meanings: (i) the term “Insured Peril” shall mean a peril actually insured against for which the insurance proceeds actually received by Landlord (and which are not required to be paid to any Lender) are sufficient (except for any “deductible” amount specified by such insurance) to restore the Project under then existing Laws to the condition existing immediately prior to the damage; and (ii) the term “Uninsured Peril” shall mean any peril which is not an Insured Peril. Notwithstanding the foregoing, if the “deductible” for earthquake or flood insurance exceeds two percent (2%) of the replacement cost of the improvements insured, such peril shall, at Landlord’s election, be deemed an “Uninsured Peril” for purposes of this Lease.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Holder’s Right to Receive Notice Nothing herein shall be construed as conferring upon the Holders the right to vote or consent or to receive notice as a shareholder for the election of directors or any other matter, or as having any rights whatsoever as a shareholder of the Company. If, however, at any time prior to the expiration of the Purchase Warrants and their exercise, any of the events described in Section 8.2 shall occur, then, in one or more of said events, the Company shall give written notice of such event at least fifteen days prior to the date fixed as a record date or the date of closing the transfer books for the determination of the shareholders entitled to such dividend, distribution, conversion or exchange of securities or subscription rights, or entitled to vote on such proposed dissolution, liquidation, winding up or sale. Such notice shall specify such record date or the date of the closing of the transfer books, as the case may be. Notwithstanding the foregoing, the Company shall deliver to each Holder a copy of each notice given to the other shareholders of the Company at the same time and in the same manner that such notice is given to the shareholders.
Right to Reject The Department reserves the right to accept or reject all proposals, or separable portions thereof, and to waive any minor irregularity, technicality, or omission if the Department determines that doing so shall serve the Department’s best interests. The Department may reject any proposal not submitted in the manner specified by the solicitation documents.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
