PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $696,243.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
CONTRACT AMOUNT AND PAYMENT FOR SERVICES 5.1 Fiscal Year 2020 Contract Amount. The total amount of HHSC's share of this Contract for fiscal year 2020 shall not exceed $3,615,665.86. LIDDA's share of this Contract for fiscal year 2020, the local match, is $289,027.35. The total value of this Contract for fiscal year 2020 shall not exceed $3,904,693.21.
Payment for Working Overtime (a) For all work done outside ordinary hours, the rates of pay will be time and a half for the first two hours and double time thereafter.
COMPENSATION FOR CONSTRUCTION PHASE SERVICES 5.1 For the Construction Manager’s performance of the Work as described in Section 2.3, the Owner shall pay the Construction Manager the Contract Sum in current funds. The Contract Sum is the Cost of the Work as defined in Section 6.1.1 plus the Construction Manager’s Fee.
Commissioning Commissioning tests of the Interconnection Customer's installed equipment shall be performed pursuant to applicable codes and standards. If the Interconnection Customer is not proceeding under Section 2.3.2, the Utility must be given at least ten (10) Business Days written notice, or as otherwise mutually agreed to by the Parties, of the tests and may be present to witness the commissioning tests.
INSTRUCTIONS FOR COMPLETING FORM A AND B Form A and Form B should be completed for Contracts for consulting services in accordance with Section XI.18.C of the Office of the State Comptroller’s Guide to Financial Operations (xxxx://xxx.xxx.xxxxx.xx.xx/agencies/guide/MyWebHelp/), “Consultant Disclosure Legislation,” and the following:
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
Payment for Services Contractor shall exert reasonable and diligent efforts to collect prompt payment from the Commonwealth. Contractor shall pay Subcontractor in proportion to amounts received from the Commonwealth which are attributable to the Services performed by Subcontractor. Contractor shall pay Subcontractor within fourteen (14) days after the Contractor receives such payment from the Commonwealth, unless the parties expressly agree upon a different payment schedule or structure as set forth below: ______________________________________________________________________________________________________________________________________________________________________________________________________________________________________.
PAYMENT FOR GOODS AND SERVICES a. DIR Customer shall comply with Chapter 2251, Texas Government Code, or applicable local law, in making payments to the Vendor. Payment under a DIR Contract shall not foreclose the right to recover wrongful payments.
