Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Notice of Litigation, Right to Prosecute, Etc No Fund shall be liable for indemnification under this Section 5.03 unless a Person shall have promptly notified such Fund in writing of the commencement of any litigation or proceeding brought against such Person in respect of which indemnity may be sought under this Section 5.03. With respect to claims in such litigation or proceedings for which indemnity by a Fund may be sought and subject to applicable law and the ruling of any court of competent jurisdiction, such Fund shall be entitled to participate in any such litigation or proceeding and, after written notice from such Fund to any Person, such Fund may assume the defense of such litigation or proceeding with counsel of its choice at its own expense in respect of that portion of the litigation for which such Fund may be subject to an indemnification obligation; provided however, a Person shall be entitled to participate in (but not control) at its own cost and expense, the defense of any such litigation or proceeding if such Fund has not acknowledged in writing its obligation to indemnify the Person with respect to such litigation or proceeding. If such Fund is not permitted to participate or control such litigation or proceeding under applicable law or by a ruling of a court of competent jurisdiction, such Person shall reasonably prosecute such litigation or proceeding. A Person shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding without providing each applicable Fund with adequate notice of any such settlement or judgment, and without each such Fund's prior written consent. All Persons shall submit written evidence to each applicable Fund with respect to any cost or expense for which they are seeking indemnification in such form and detail as such Fund may reasonably request.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.
GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.
Retention of Records, Right to Monitor and Audit (a) CONTRACTOR shall maintain all required records for three (3) years after the COUNTY makes final payment and all other pending matters are closed, and shall be subject to the examination and/or audit of the County, a Federal grantor agency, and the State of California.
Disputes and Remedies 6.01 Agreement of the Parties The Parties agree that the interests of fairness, efficiency, and good business practices are best served when the Parties employ all reasonable and informal means to resolve any dispute under the Contract before resorting to formal dispute resolution processes otherwise provided in the Contract. The Parties will use all reasonable and informal means of resolving disputes prior to invoking a remedy provided elsewhere in the Contract, unless HHSC immediately terminates the Contract in accordance with the terms and conditions of the Contract. Any dispute, that in the judgment of any Party to the Agreement, may materially affect the performance of any Party will be reduced to writing and delivered to the other Party within 10 business days after the dispute arises. The Parties must then negotiate in good faith and use every reasonable effort to resolve the dispute at the managerial or executive levels prior to initiating formal proceedings pursuant to the UTC and Texas Government Code §2260, unless a Party has reasonably determined that a negotiated resolution is not possible and has so notified the other Party. The resolution of any dispute disposed of by agreement between the Parties will be reduced to writing and delivered to all Parties within 10 business days of such resolution.
Right to Set Off Notwithstanding anything to the contrary in this License Agreement, each Party has the right at all times to retain and set off against all amounts due and owing to the other Party as determined in a final judgment any damages recovered by such Party for any Losses incurred by such Party.
Restoration of Rights on Abandonment of Proceedings In case the Trustee shall have proceeded to enforce any right under this Indenture and such proceedings shall have been discontinued or abandoned for any reason, or shall have been determined adversely to the Trustee, then and in every such case the Issuer and the Trustee shall be restored respectively to their former positions and rights hereunder, and all rights, remedies and powers of the Issuer, the Trustee and the Securityholders shall continue as though no such proceedings had been taken.
