Delivery of Products 4.1 The Supplier shall ensure that:
(a) Products are properly packed and secured in such manner as to enable them to reach their destination in good condition;
(b) each delivery of Products is accompanied by a delivery note which shows the date of the Order, the Order number (if any), the type and quantity of Products (including the code number of the Products, where applicable), special storage instructions (if any) and, if the Products are being delivered in instalments, the outstanding balance of Products remaining to be delivered; and
(c) it states clearly on the delivery note any requirement for Ornua to return any packaging material for the Products to the Supplier. Any such packaging material shall only be returned to the Supplier at the cost of the Supplier.
4.2 The Supplier shall deliver the Products:
(a) to the location set out in the Order or such other location as the parties may agree which may include delivery to a carrier (Delivery Location); and
(b) on the date specified in the Order or, if no such date is specified, on a date agreed with Ornua in advance (Delivery Date). Delivery shall be on a Business Day during normal business hours, unless agreed otherwise with Ornua or otherwise instructed by Ornua.
4.3 Delivery of Products shall be completed when the Supplier unloads and stacks the Products at the Delivery Location, unless different delivery terms (or Incoterms®) are specified in the Order.
4.4 Ornua operates a “Just-in-Time” delivery system. Time shall be of the essence in relation to the Delivery Date and any agreed delivery time. If the Products are not delivered on time by the Supplier, clause 6.1 shall apply.
4.5 If the Supplier delivers more that the quantity of Products ordered, Ornua shall not be bound to pay for the excess and any excess shall be and shall remain at the Supplier’s risk and shall be returnable at the Supplier’s expense.
4.6 The Supplier shall not deliver Products in instalments without Ornua's prior written consent. Where it is agreed that Products are to be delivered in instalments, they may be invoiced and paid for separately. Failure by the Supplier to deliver any one instalment on time or at all or any defect in an instalment shall entitle Ornua to the remedies set out in clause 6.1.
4.7 Title and risk in the Products shall pass to Ornua on completion of delivery.
Delivery of Product 11.1 Subject to Clause 25 (Capacity Constraints), GSK (or the Nominated Supplier) shall Deliver the Products on the date specified in the relevant Firm Order, provided that:
(A) the quantity of Product Delivered by GSK may vary by [***] from the quantity specified in the relevant Firm Order; and
(B) the date of Delivery may vary by [***] from the date specified in the relevant Firm Order, and such variance shall not constitute a breach of this Agreement by GSK or entitle the Purchaser to reject such Delivery. Delivery of Commercial API and Commercial Products shall take place following release by GSK of such Products in accordance with (and the extent required by) the Quality Agreement, provided that, for clarity, the Purchaser shall only be required to pay for the quantity of Product that is actually Delivered.
11.2 In respect of Commercial API, the Parties may agree that some or all of the quantities of such Commercial API Delivered pursuant to Clause 11.1 shall remain in the possession of GSK or its Affiliate on [***]. The Purchaser shall pay GSK a storage fee to cover any GSK costs and expenses incurred in connection with holding and storing such [***] stock (“Storage Fee”). The Storage Fee is set forth in Schedule 4 (Fees). For the avoidance of doubt, no Storage Fee is payable in respect of quantities of Commercial API required for the Manufacture of the Commercial Product shown in the Firm Zone and that are held by GSK at designated Manufacturing Site in respect of Commercial Product for the purposes of such Manufacture. CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY [***], HAS BEEN OMITTED BECAUSE DERMAVANT SCIENCES LTD. HAS DETERMINED THE INFORMATION (I) IS NOT MATERIAL AND (II) WOULD LIKELY CAUSE COMPETITIVE HARM TO DERMAVANT SCIENCES LTD. IF PUBLICLY DISCLOSED.
11.3 Subject to paragraph 2 of Schedule 3 (Toll Manufacturing Provisions), the risk in and title to the Commercial Products shall remain with GSK (or its Affiliate) until Delivered, at which point it shall pass to the Purchaser. Title to Commercial API shall pass to the Purchaser when such Commercial API is purchased by Purchaser, but risk in such Commercial API shall remain with GSK in accordance with Clause 8.5 for so long as such Commercial API is in GSK’s possession as Purchaser Materials.
11.4 Other than in respect of Commercial API that the Parties agree shall be retained by GSK on Consignment, the Purchaser shall collect the Products Delivered from the Manufacturing Site on the date of Delivery, or such date as GSK, the Nominated Supplier or the Nominated Manufacturer may notify to the Purchaser (provided that, and if the Delivery date notified to the Purchaser is earlier or later than the Delivery window contemplated by Clause 11.1, the Delivery date must be agreed with the Purchaser). Notwithstanding the foregoing, and without limiting Clause 20.2, Purchaser may, [***], elect to obtain Delivery at any point within [***] of the notified date of Delivery by providing notice to GSK of such revised Delivery date.
11.5 Commercial API that the Parties agree shall be retained by GSK [***] at the Manufacturing Site in respect of Commercial API shall be collected by the Purchaser from such Manufacturing Site on such date as may be agreed between the Parties.
11.6 For the avoidance of doubt, irrespective of whether or not any quantity of Commercial API is retained by GSK [***] for a period of time after Delivery, the Purchaser shall be responsible for the delivery of Toll Materials to the designated Manufacturing Site in respect of Commercial Product.
Shipment and Delivery Seller grants the Company the right at any time to specify the carrier and/or method of transportation to be employed in conveying any part or all of the Goods covered herein. In the event that Seller uses an unauthorized carrier and/or method of transportation, then all shipping expenses shall be assumed by Seller. Unless otherwise stated in the Order, all Goods will be shipped FCA shipment point. FCA shall be interpreted in accordance with the version of Incoterms valid at the time of the Seller’s acceptance of the Order. The Seller shall be responsible for preparing and filing all export documentation for all shipments. The Company shall not be obligated to accept early deliveries, partial deliveries or excess deliveries. If Goods are incorrectly delivered, the Seller shall be responsible for any additional expense incurred in delivering the Goods to the correct destination. The delivery date set forth on the Order is of the essence of the Contract. If the Seller anticipates that it will not be able to deliver the Goods upon the agreed delivery date, then the Seller shall immediately notify the Company thereof in writing; provided, however, that such notice shall not relieve the Seller of its responsibilities and liabilities with respect to on-time delivery hereunder. In such event, the Company may request that the Seller expedite delivery to the maximum extent possible at the Seller’s sole expense. If the Seller does not deliver the Goods by the agreed delivery date, then the Company shall be entitled to liquidated damages as agreed between the parties, up to and including the total Order value. Notwithstanding the foregoing, the Company reserves the right to claim repayment for any and all costs, losses, expenses and damages incurred by the Company that are attributable to the Seller’s delay in delivery. Such liquidated damages shall be paid at the Company’s written demand. Partial deliveries shall not relieve the Seller from liability for any late delivery hereunder. If the Seller discovers that it has shipped any non-conforming Goods to the Company, it shall immediately (and not more than 24 hours after such discovery) notify the Company thereof in writing; provided, however, that such notice shall not relieve the Seller of its responsibilities and liabilities with respect to defective goods hereunder.
Transportation and Delivery Prices shall include all charges for packing, handling, freight, distribution, and inside delivery. Transportation of goods shall be FOB Destination to any point within thirty (30) days after the Customer places an Order. A Contractor, within five (5) days after receiving a purchase order, shall notify the Customer of any potential delivery delays. Evidence of inability or intentional delays shall be cause for Contract cancellation and Contractor suspension.
Shipping and Delivery a. The prices are the delivered price to any Purchasing Entity. All deliveries shall be F.O.B. destination, freight pre-paid, with all transportation and handling charges paid by the Contractor. Responsibility and liability for loss or damage shall remain the Contractor’s until final inspection and acceptance when responsibility shall pass to the Purchasing Entity except as to latent defects, fraud and Contractor’s warranty obligations. The minimum shipment amount, if any, will be found in the special terms and conditions. Any order for less than the specified amount is to be shipped with the freight prepaid and added as a separate item on the invoice. Any portion of an Order to be shipped without transportation charges that is back ordered shall be shipped without charge.
b. All deliveries will be “Inside Deliveries” as designated by a representative of the Purchasing Entity placing the Order. Inside Delivery refers to a delivery to other than a loading dock, front lobby, or reception area. Specific delivery instructions will be noted on the order form or Purchase Order. Any damage to the building interior, scratched walls, damage to the freight elevator, etc., will be the responsibility of the Contractor. If damage does occur, it is the responsibility of the Contractor to immediately notify the Purchasing Entity placing the Order.
c. All products must be delivered in the manufacturer’s standard package. Costs shall include all packing and/or crating charges. Cases shall be of durable construction, good condition, properly labeled and suitable in every respect for storage and handling of contents. Each shipping carton shall be marked with the commodity, brand, quantity, item code number and the Purchasing Entity’s Purchase Order number.
Services and Deliverables The Services and the required Deliverables for the Services are specified below. Service Type Output Measure Quantity per annum Number of Service Users Funding amount per annum (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $ Service Type Output Measure Quantity per annum Number of Service Users Funding amount (excl. GST) $ $ $ Description of Services Funding amount one-off (excl. GST) $ *Note: Refer to clause 4.8 in the Funding and Service Details about permitted variations in output quantities.
Supply of Products
3.1 The Supplier warrants that the Products shall:
(a) correspond with their description and any applicable Product Specification;
(b) conform in all respects with the Order and any relevant sample;
(c) be of satisfactory quality and fit for any purpose held out by the Supplier or made known to the Supplier by Ornua, expressly or by implication, and in this respect Ornua relies on the Supplier's skill and judgement;
(d) be manufactured by properly trained and qualified personnel using all reasonable skill, care and diligence and in a good and workmanlike manner;
(e) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for the period set out in the Product Specification or, if none is specified, for at least 12 months after delivery;
(f) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Products;
(g) comply with all relevant standards including any UK Standards, European Standards or International Standards applicable in the UK and the country or State where the Products are to be used; and
(h) in the case of Products containing food stuffs, when delivered to Ornua, comply with all applicable food and hygiene legislation and regulations and best industry practice.
3.2 The Supplier shall ensure that at all times it has and maintains all licences, permissions, authorisations, consents and permits needed to carry out its obligations under the Contract in respect of the supply of Products. Breach of this Condition shall be deemed a material breach of the Contract.
3.3 Ornua may inspect and test the Products at any time before delivery. The Supplier shall remain fully responsible for the Products despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing Ornua considers that the Products do not comply or are unlikely to comply with the Supplier's undertakings at clause 3.1, Ornua shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 Ornua may conduct further inspections and tests after the Supplier has carried out its remedial actions.
Delivery of Invoices Such Grantor will deliver to the Administrative Agent immediately upon its request after the occurrence and during the continuation of an Event of Default duplicate invoices with respect to each Account owned by it bearing such language of assignment as the Administrative Agent shall specify.
Orders and Delivery 4.1 The Purchaser may from time to time place Purchase Orders on the Supplier for the Goods and/or Services. Nothing in this Agreement shall prevent the Purchaser from purchasing the same or similar goods and services from a third party.
4.2 The Purchaser may at any time terminate a PO, or where applicable this Agreement, for convenience if the relevant contract in terms whereof Goods and/or Services are on-sold by the Purchaser to a Customer is terminated, by giving the Supplier 30 (thirty) days’ written notice to such effect, in which event the Purchaser shall be liable to pay only for Goods ordered under Purchase Orders placed prior to the delivery of such notice of termination.
4.3 The Goods to be supplied pursuant to this Agreement shall be delivered by the Supplier DDP Delivered Duty Paid (at the Purchaser’s or the Customer’s premises, Gauteng) on or before the delivery date/s stated in the relevant PO or delivery schedule. Time is of the essence in the performance of the Supplier’s obligations.
4.4 Subject to the Supplier’s strict compliance with this clause 4, the Purchaser shall grant to the Supplier an extension of time if and to the extent that delivery is or will be delayed by the following causes:
4.4.1 Additional Goods and/or Services are ordered under clause 5, or
4.4.2 Any delay, impediment or prevention caused by either force majeure or the Purchaser occurs.
4.5 If the Supplier considers itself entitled to an extension of time, the Supplier shall give notice to the Purchaser describing the event or circumstance giving rise to the requested extension of time (in this clause referred to as the “claim”). The notice shall be given as soon as practicable, and in any event not later than 2 (two) days after the Supplier became aware, or should have become aware, of the event or circumstance.
4.6 Within 7 (seven) days after the Supplier sent the notice referred to in clause 4.5 or within such other period as may be proposed by the Supplier and approved by the Purchaser, the Supplier shall send to the Purchaser a fully detailed claim and revised draft delivery schedule which includes full supporting particulars of the basis and duration of the claim. If the event or circumstance giving rise to the claim has a continuing effect:
4.6.1 this fully detailed claim shall be considered as interim;
4.6.2 the Supplier shall send further interim claims at weekly intervals, giving the accumulated delay, and such further particulars as the Purchaser may reasonably require; and
4.6.3 the Supplier shall send a final claim within 7 (seven) days after the end of the effects resulting from the event or circumstance, or within such other period as may be proposed by the Supplier and approved by the Purchaser.
4.7 Within 7 (seven) days after receiving a claim or any further particulars supporting a previous claim, or within such other period as may be proposed by the Purchaser and approved by the Supplier, the Purchaser shall respond with approval, or with disapproval and detailed comments. It may also request further clarification or additional particulars. Should the Purchaser fail to respond within the stated time, it shall be deemed to have rejected the claim.
4.8 A revised delivery schedule shall only become valid and binding once approved by the Purchaser, which approval shall not be unreasonably withheld.
Delivery of Materials In the event of any expiration or termination of this Agreement, Contractor shall promptly provide the JBE with all originals and copies of the Deliverables, including any partially-completed Deliverables-related work product or materials, and any JBE-provided materials in its possession, custody, or control. In the event of any termination of this Agreement, the JBE shall not be liable to Contractor for compensation or damages incurred as a result of such termination; provided that if the JBE’s termination is not for cause, the JBE shall pay any fees due under this Agreement for Services performed or Deliverables completed and accepted as of the date of the JBE’s termination Notice.
