Client’s Responsibilities In addition to other responsibilities herein or imposed by law, the Client shall:
(a) Designate in writing a person to act as its representative, such person having complete authority to transmit instructions, receive information, and make or interpret the Client's decisions.
(b) Provide all information and criteria as to the Client's requirements, objectives, and expectations for the project and all standards of development, design, or construction.
(c) Provide the Consultant all available studies, plans, or other documents pertaining to the project, such as surveys, engineering data, environmental information, etc., all of which the Consultant may rely upon.
(d) Arrange for access to the site and other property as required for the Consultant to provide its services.
(e) Review all documents or reports presented by the Consultant and communicate decisions pertaining thereto within a reasonable time so as not to delay the Consultant.
(f) Furnish approvals and permits from governmental authorities having jurisdiction over the project and approvals and consents from other parties as may be necessary.
(g) Obtain any independent accounting, legal, insurance, cost estimating and feasibility services required by Client.
(h) Give prompt written notice to the Consultant whenever the Client becomes aware of any development that affects the Consultant's services or any defect or noncompliance in any aspect of the project.
Responsibility for Use (a) The Company alone will be responsible for furnishing, or arranging for a third party to furnish, all data and information required by the Documentation and the specifications therein for the Licensed System to function and perform in accordance with the Documentation, other than the data and information residing in the Licensed System in connection with BNYM’s performance of the Core Services. BNYM shall have no liability or responsibility for any Loss caused in whole or in part by the Company’s or a Permitted User’s exercise of the Licensed Rights or use of the Licensed System or by data or information of any nature inputted into the Licensed System by or under the direction or authorization of Company or a Permitted User; provided, however, this Section 2.5 shall not relieve BNYM of its obligation to act in accordance with its obligations under the Main Agreement. Company shall be responsible and solely liable for the cost or expense of regenerating any output or other remedial action if the Company, a Permitted User or an agent of either shall have failed to transmit properly and in the correct format any data or information, shall have transmitted erroneous or incorrect information or data, or shall have failed to timely verify or reconcile any such data or information when it is generated by the Licensed System (“Data Faults”).
Responsibility for Content Vendor is solely responsible for administration, content, intellectual property rights, and all materials at Vendor’s website. DIR reserves the right to require a change of listed content if, in the opinion of DIR, it does not adequately represent the Contract.
No Responsibility for Certain Matters No Agent shall be responsible to any Lender for the execution, effectiveness, genuineness, validity, enforceability, collectibility or sufficiency of this Agreement or any other Loan Document or for any representations, warranties, recitals or statements made herein or therein or made in any written or oral statements or in any financial or other statements, instruments, reports or certificates or any other documents furnished or made by such Agent to Lenders or by or on behalf of Company to such Agent or any Lender in connection with the Loan Documents and the transactions contemplated thereby or for the financial condition or business affairs of Company or any other Person liable for the payment of any Obligations, nor shall such Agent be required to ascertain or inquire as to the performance or observance of any of the terms, conditions, provisions, covenants or agreements contained in any of the Loan Documents or as to the use of the proceeds of the Loans or the use of the Letters of Credit or as to the existence or possible existence of any Event of Default or Potential Event of Default. Anything contained in this Agreement to the contrary notwithstanding, Administrative Agent shall not have any liability arising from confirmations of the amount of outstanding Loans or the Letter of Credit Usage or the component amounts thereof.
Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.
CONSULTANT’S RESPONSIBILITIES In addition to all other obligations contained herein, the Consultant agrees, warrants, and represents that:
6.1 The Consultant will furnish all material, equipment, labor and supplies in such quantities and of the proper quality to professionally and timely perform the Services, except as otherwise mutually agreed by the Parties;
6.2 The Consultant shall perform the Services with the professional skill and care ordinarily provided by competent consultants practicing in the same or similar locality and under the same or similar circumstances and professional license;
6.3 The Consultant will comply with the provisions of all federal, state, and local laws, regulations, ordinances, requirements and codes which are applicable to its performance of Services;
6.4 The Consultant is not and will not be bound by any agreement and has not assumed nor will assume any obligation which would, in any way, restrict its ability to perform the Services or be inconsistent with the Services;
6.5 In performing the Services, the Consultant will not use any third party’s confidential or propriety information, or infringe the rights of another party, nor will the Consultant disclose to the Authority, or bring onto the Authority’s premises, or induce the Authority to use any third party’s confidential or proprietary information;
6.6 The Consultant does not have the authority to act for the Authority, bind the Authority in any respect, or incur any debts or liabilities in the name of or on behalf of the Authority, except as otherwise expressly authorized in writing by the Authority;
6.7 Consultant is an independent contractor for the performance of his duties under this Contract. Accordingly, the Consultant shall be responsible for payment of all taxes including federal, state and local taxes arising out of the Consultant’s activities in accordance with this Contract. Consultant is responsible for payment of the compensation, including any withholding, Social Security, or other taxes on such compensation, of any subcontractors retained by Consultant, or Consultant's employees performing Services consistent with its status as an independent contractor and in compliance with all applicable laws and regulations;
6.8 Consultant has and hereby retains full control of any supervision over the Consultant’s obligations hereunder and over any persons employed or subcontracted by the Consultant for performing Services hereunder;
6.9 Consultant will in no way be considered an agent, partner, joint venturer, or employee of Authority at any time during the Term. Consultant will not undertake to commit Authority to any course of action in relation to a third party unless expressly requested and authorized to do so by the Authority in writing.
6.10 As of the Effective Date and at all times while providing Services hereunder, the Consultant shall possess and maintain in good standing any and all licenses or other authorizations and approvals necessary to perform the Services.
Responsibility for documentation None of the Security Agent, any Receiver nor any Delegate is responsible or liable for:
(a) the adequacy, accuracy or completeness of any information (whether oral or written) supplied by the Security Agent, an Obligor or any other person in or in connection with any Finance Document or the transactions contemplated in the Finance Documents or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document;
(b) the legality, validity, effectiveness, adequacy or enforceability of any Finance Document, the Transaction Security or any other agreement, arrangement or document entered into, made or executed in anticipation of, under or in connection with any Finance Document or the Transaction Security; or
(c) any determination as to whether any information provided or to be provided to any Secured Party is non-public information the use of which may be regulated or prohibited by applicable law or regulation relating to insider dealing or otherwise.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.
Customer Responsibility You agree that you are responsible for all access to and use of the Service through your account or password(s) and for any fees incurred for the Service, or for software or other merchandise purchased through the Service, or any other expenses incurred in accordance with the terms of this Agreement. You agree that you are responsible for backing up (a) any data you submit, receive or transfer over the Service, including, without limitation, your email; and (b) any data, files, programs, or applications on any device you connect to the Service. You acknowledge that you are aware that content accessible on or through the Service may contain material that is unsuitable for minors (persons under 18 years of age). You agree to supervise usage of your account by minors. You ratify and confirm any obligations incurred by a minor using your account.