Additional Acceptable Uses of Student Data Contractor is prohibited from using Student Data for any secondary use not described in this agreement except: a. for adaptive learning or customized student learning purposes; b. to market an educational application or product to a parent or legal guardian of a student if Contractor did not use Data, shared by or collected per this Contract, to market the educational application or product; c. to use a recommendation engine to recommend to a student i. content that relates to learning or employment, within the third-party contractor's internal application, if the recommendation is not motivated by payment or other consideration from another party; or
Required Procurement Procedures for Obtaining Goods and Services The Grantee shall provide maximum open competition when procuring goods and services related to the grant- assisted project in accordance with Section 287.057, Florida Statutes.
Computer Equipment Recycling Program If this Contract is for the purchase or lease of computer equipment, then Contractor certifies that it is in compliance with Subchapter Y, Chapter 361 of the Texas Health and Safety Code related to the Computer Equipment Recycling Program and the Texas Commission on Environmental Quality rules in 30 TAC Chapter 328.
Preventive Care and Early Detection Services This plan covers, early detection services, preventive care services, and immunizations or vaccinations in accordance with state and federal law, including the Affordable Care Act (ACA), as set forth below and in accordance with the guidelines of the following resources: • services that have an A or B rating in the current recommendations of the U.S. Preventative Services Task Force (USPSTF); • immunizations recommended by the Advisory Committee on Immunization Practices of the Centers for Disease Control and Prevention; • preventive care and screenings for infants, children, and adolescents as outlined in the comprehensive guidelines supported by the Health Resources and Services Administration (HRSA); or • preventive care and screenings for women as outlined in the comprehensive guidelines as supported by HRSA. Covered early detection services, preventive care services and adult and pediatric immunizations or vaccinations are based on the most currently available guidelines and are subject to change. The amount you pay for preventive services will be different from the amount you pay for diagnostic procedures and non-preventive services. See the Summary of Medical Benefits and the Summary of Pharmacy Benefits for more information about the amount you pay. This plan covers the following preventive office visits. • Annual preventive visit - one (1) routine physical examination per plan year per • Pediatric preventive office and clinic visits from birth to 35 months - 11 visits; • Well Woman annual preventive visit - one (1) routine gynecological examination per plan year per female member.
Work on Scheduled RDOs Circumstances (a) Work may take place on a scheduled RDO by agreement between the Parties to this Agreement or on any substituted day where it is required by the Employer and such work is necessary to meet operational requirements, manage its business and/or improve productivity subject to the below procedure. (b) Examples of where work may take place include, but are not limited to, the following: (i) to allow other Employees to be employed productively, to carry out out-of-hours maintenance; or (ii) because of unforeseen delays to a particular Project or a section of it; or (iii) for other reasons arising from unforeseen or emergency circumstances on a Project. For the avoidance of doubt, unforeseen or emergency circumstances include, but are not limited to: excessive periods of Inclement Weather, matters not necessarily the fault of the Employer which has led to the Project being delayed or behind schedule, the requirement to meet the Employer’s work program and unexpected delays in the Project due to scheduling of other works or supply of materials, or work that cannot be performed on other days because of municipal council restrictions, or other relevant laws or regulations. Such requirement must be based on genuine circumstances. (c) Where the Employer requires work to be performed on a Scheduled RDO (or any substituted day) because of the existence of any of the above, it will: (i) consult with the affected Employees and the Union within a reasonable timeframe; (ii) determine that affected Employees agree to work on the Scheduled RDO; and (iii) the Employer will notify and agree with the Employees and their Union representative in writing (via email prior to the RDO when work needs to be performed. The attached notification form (Appendix I) may be used for this purpose. Affected Employees will be entitled to meet with their Union Representative for the purpose of consulting about works to occur on a scheduled RDO. The attached notification form (Appendix I) may be used for this purpose. (d) The Employer is committed to providing as much notice as is reasonably practicable of a requirement to work. Wherever possible, the process outlined above will occur at least nine (9) calendar days prior to the RDO in question. An Employee may refuse to work on a scheduled RDO (or any substituted day) if the requirement to do so is plainly unreasonable having regard to: (i) the hours of work that will be worked by that Employee in the week of the scheduled RDO; (ii) the number of scheduled RDOs worked by the Employee within the previous six weeks; (iii) the Employee’s family responsibilities; and (iv) any other special circumstances peculiar to the Employee. (e) An Employee required to work who has been consulted with in accordance with the Procedure, in addition to accrued entitlements, will be paid at the Employee’s Ordinary Rate prescribed in this Agreement for the Employees’ classification. (f) An Employee required to work who has not been consulted with in accordance with the Procedure, in addition to accrued entitlements, will be paid as if they were undertaking Public Holiday Work in accordance with clause 39.9 of this Agreement. For the avoidance of doubt, where the Employer has consulted with the Union in accordance with subclause
How Do I Get More Information? This Notice summarizes the Action, the terms of the Settlements, and your rights and options in connection with the Settlements. More details are in the Settlement Agreements, which are available for your review at xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx. The Settlement Website also has the Second Amended Complaint and other documents relating to the Settlements. You may also call toll-free 0-000-000-0000 or write the Claims Administrator at: Financial Aid Antitrust Settlements, c/o Claims Administrator, 0000 Xxxx Xxxxxx, Xxxxx 0000, Xxxxxxxxxxxx, XX 00000. EXHIBIT B To: Settlement Class Member Email Address From: Claims Administrator Subject: Notice of Proposed Class Action Settlement – Xxxxx, et al. x. Xxxxx University, et al. Please visit xxx.XxxxxxxxxXxxXxxxxxxxxXxxxxxxxxx.xxx for more information. • The Court has preliminarily approved proposed settlements (“Settlements”) with the following six schools: Brown University, the University of Chicago, the Trustees of Columbia University in the City of New York, Duke University, Emory University, and Yale University (collectively the “Settling Universities”). • The Court has also preliminarily approved a class of students who attended one or more of the Settling Universities during certain time periods. This is referred to as the “Settlement Class,” which is defined in more detail below.
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Program Location A. Unless otherwise agreed upon in writing, the parties acknowledge and agree that the Work of this Agreement will be performed at the following Property address: Ktr Address1 Address2
Unbundled Loop Modifications (Line Conditioning 2.5.1 Line Conditioning is defined as routine network modification that BellSouth regularly undertakes to provide xDSL services to its own customers. This may include the removal of any device, from a copper Loop or copper Subloop that may diminish the capability of the Loop or Subloop to deliver high-speed switched wireline telecommunications capability, including xDSL service. Such devices include, load coils, excessive bridged taps, low pass filters, and range extenders. Excessive bridged taps are bridged taps that serves no network design purpose and that are beyond the limits set according to industry standards and/or the BellSouth’s TR 73600 Unbundled Local Loop Technical Specification. 2.5.2 BellSouth will remove load coils only on copper Loops and Subloops that are less than eighteen thousand (18,000) feet in length. 2.5.3 For any copper loop being ordered by NewPhone which has over six thousand (6,000) feet of combined bridged tap will be modified, upon request from NewPhone, so that the loop will have a maximum of six thousand (6,000) feet of bridged tap. This modification will be performed at no additional charge to NewPhone. Loop conditioning orders that require the removal of bridged tap that serves no network design purpose on a copper Loop that will result in a combined total of bridged tap between two thousand five hundred (2,500) and six thousand (6,000) feet will be performed at the rates set forth in Exhibit A. 2.5.4 NewPhone may request removal of any unnecessary and non-excessive bridged tap (bridged tap between zero (0) and two thousand five hundred (2,500) feet which serves no network design purpose), at rates pursuant to BellSouth’s SC Process as mutually agreed to by the Parties. 2.5.5 Rates for ULM are as set forth in Exhibit A. 2.5.6 BellSouth will not modify a Loop in such a way that it no longer meets the technical parameters of the original Loop type (e.g., voice grade, ADSL, etc.) being ordered. 2.5.7 If NewPhone requests ULM on a reserved facility for a new Loop order, BellSouth may perform a pair change and provision a different Loop facility in lieu of the reserved facility with ULM if feasible. The Loop provisioned will meet or exceed specifications of the requested Loop facility as modified. NewPhone will not be charged for ULM if a different Loop is provisioned. For Loops that require a DLR or its equivalent, BellSouth will provide LMU detail of the Loop provisioned. 2.5.8 NewPhone shall request Loop make up information pursuant to this Attachment prior to submitting a service inquiry and/or a LSR for the Loop type that NewPhone desires BellSouth to condition. 2.5.9 When requesting ULM for a Loop that BellSouth has previously provisioned for NewPhone, NewPhone will submit a SI to BellSouth. If a spare Loop facility that meets the Loop modification specifications requested by NewPhone is available at the location for which the ULM was requested, NewPhone will have the option to change the Loop facility to the qualifying spare facility rather than to provide ULM. In the event that BellSouth changes the Loop facility in lieu of providing ULM, NewPhone will not be charged for ULM but will only be charged the service order charges for submitting an order.
Emergency/Declared Disaster Requirements In the event of an emergency or if Orange County is declared a disaster area by the County, state or federal government, this Contract may be subjected to unusual usage. The Contractor shall service the County during such an emergency or declared disaster under the same terms and conditions that apply during non-emergency/disaster conditions. The pricing quoted by the Contractor shall apply to serving the County’s needs regardless of the circumstances. If the Contractor is unable to supply the goods/services under the terms of the Contract, then the Contractor shall provide proof of such disruption and a copy of the invoice for the goods/services from the Contractor’s supplier(s). Additional profit margin as a result of supplying goods/services during an emergency or a declared disaster shall not be permitted. In the event of an emergency or declared disaster, emergency purchase order numbers will be assigned. All applicable invoices from the Contractor shall show both the emergency purchase order number and the Contract number.
