Payment of Project Costs and GST Sample Clauses

Payment of Project Costs and GST. (a) The City and CSERELP will contribute funding equal to their share of respective Project Costs as set out in Section 5.1 to the Project Account, in accordance with the Development Management Agreement and will pay all required Advances pursuant to the Development Management Agreement. (b) In the event that GST or any other sales or use tax is applicable to any amounts payable to any Party hereunder after assessing all reasonably available exemptions, such taxes shall be payable in respect of (and in addition to) such amounts. Each of the Parties shall comply with the Excise Tax Act (Canada) and regulations thereunder (as the same may be amended, replaced or any successor legislation from time to time) and all other legislation and regulations applicable to GST from to time (in this Section, collectively, the “GST Act”) and shall pay applicable GST on all amounts payable by such Parties under this Agreement, and each of the Parties shall comply with the Income Tax Act (Canada) and regulations thereunder (as the same may be amended, replaced or any successor legislation from time to time) and all other legislation and regulations applicable to income tax from to time (in this Section, collectively, the “ITA”). Each of the Parties (in this Section, the “Indemnifying Party”) shall indemnify and hold harmless the other Party, and its respective officers and employees (in this Section, each an “Indemnified Party”), from and against any and all actions, suits, claims, judgments, damages, penalties, interest, fines, assessments, reassessments, costs and expenses (in this Section, a “Tax Claim”), that the Indemnified Party may suffer, sustain, pay or incur, arising from or in respect of the failure of the Indemnifying Party to: (a) comply with the GST Act or the ITA Act in any respect;
Sample 1
AutoNDA by SimpleDocs

Related to Payment of Project Costs and GST

  • Payment of Project Activities County will reimburse Subrecipient for eligible project-related costs only. Subrecipient shall submit requests for reimbursement to County on a monthly basis beginning on August 1, 2021, and must provide adequate documentation as required by County in accordance with the OC Community Resources Contract Reimbursement Policy, as set forth in Exhibit 1, attached hereto and incorporated herein by reference. In addition, Subrecipient will provide a progress Grantee Performance Report (“GPR Information Form”) for the time period covered, as prescribed by County. Failure to provide any of the required documentation and reporting will cause County to withhold all or a portion of a request for reimbursement, or return the entire reimbursement package to Subrecipient, until such documentation and reporting has been received and approved by County.

  • Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.

  • Disbursements to Contractors to Pay Costs of the Project The Recipient shall require that as work on the Project and as specified in its contract is performed a Contractor shall promptly submit a detailed project specific invoice to the Project Manager. Within three (3) Business Days following receipt of such invoice from a Contractor, the Project Manager shall review the invoice and, if found to be accurate, shall so certify in writing, forwarding such certification together with a copy of the invoice to the Chief Fiscal Officer. Within five (5) Business Days following receipt of such invoice and certification from the Project Manager, the Chief Fiscal Officer shall conduct such reviews as he considers appropriate and, if he approves such invoice, shall submit to the Director a Disbursement Request together with the information and certifications required by this Section 6(b). The dollar amount set forth in the Disbursement Request shall be calculated based on the Participation Percentage as set forth originally in Appendix D of this Agreement or as may be adjusted from time to time to account for changed conditions in the project financing scheme. Within five (5) Business Days following receipt of the Disbursement Request and all required information and certifications, the Director shall, if such items are deemed by the Director to be accurate and completed, initiate a voucher in accordance with applicable State requirements for the payment of the amount set forth in the Disbursement Request. Upon receipt of a warrant from the Auditor of State drawn in connection with a voucher initiated in accordance with the terms of the preceding sentence, the Director shall forward it by regular first class United States mail or electronic funds transfer, to the contractor or other authorized recipient designated in the Disbursement Request. Prior to any disbursement from the Fund, the following documents shall be submitted to the Director by the Recipient: (i) If the request is for disbursement to a Contractor, an invoice submitted to the Recipient by the Contractor which invoice requests payment of such sums in connection with its performance of the Project; (ii) If the request is for disbursement to the Recipient pursuant to Paragraph (A)(4)(b) of Rule 164-1-22 of the Administrative Code, a xxxx of sale, paid invoice or other evidence satisfactory to the Director that payment of such sums has been made by the Recipient in connection with the portion of the Project for which payment is requested; (iii) The Project Manager's certification pursuant to Section 6(b) of this Agreement; (iv) The Disbursement Request Form and Certification in the form set forth as Appendix E of this Agreement properly executed by the Chief Fiscal Officer and the Chief Executive Officer; and (v) Such other certificates, documents and other information as the Director may reasonably require. If the Director finds that the documents are in compliance with the requirements of this Agreement, the Director is authorized and directed to cause the disbursement of moneys from the Fund for payment of the identified Project costs. A copy of all such documents submitted to the Director shall be retained by the Director. The Recipient represents that the Project was initially constructed, installed or acquired by the Recipient no earlier than the execution date of this Agreement.

  • Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items: 9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.

  • Completion of Project This Grant Agreement shall terminate upon completion of the project and payment of the last invoice.

  • Default – Reprocurement Costs In case of Contract breach by Contractor, resulting in termination by the County, the County may procure the goods and/or services from other sources. If the cost for those goods and/or services is higher than under the terms of the existing Contract, Contractor will be responsible for paying the County the difference between the Contract cost and the price paid, and the County may deduct this cost from any unpaid balance due the Contractor. The price paid by the County shall be the prevailing market price at the time such purchase is made. This is in addition to any other remedies available under this Contract and under law.

  • Sellers’ Costs and Expenses Except as may otherwise be provided in this Agreement, including Section 8.1, or in the Purchase Agreement, all expenses and costs incurred by the Sellers in connection with the performance of their obligations hereunder shall be the responsibility of, paid by and for the account of the Sellers.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.

  • Development Costs Licensee shall be responsible for all of its costs and expenses in connection with the Development of, and obtaining and maintaining Regulatory Approvals for, the Licensed Products in the Field in the Territory.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!